OPTION AGREEMENT
THIS OPTION AGREEMENT (“
Agreement ”) is entered into as of January 31,
2008, and is by and among Holly Corporation, a Delaware corporation
(“ Holly ”), Holly UNEV Pipeline Company, a
Delaware corporation (“ Holly UNEV ”), Navajo
Pipeline Co., L.P., a Delaware limited partnership, Holly Logistic
Services, L.L.C., a Delaware limited liability company (“
Holly GP ”), HEP Logistics Holdings, L.P., a Delaware
limited partnership (the “ General Partner ”),
Holly Energy Partners, L.P., a Delaware limited partnership (the
“ Partnership ”), HEP Logistics GP, L.L.C., a
Delaware limited liability company (the “ OLP GP
”), and Holly Energy Partners–Operating, L.P., a
Delaware limited partnership (“ HEP-Operating
”). The above-named entities are sometimes referred to in
this Agreement each as a “ Party ” and
collectively as the “ Parties .”
R
E C I T A L S:
1. Certain of the Parties are
also parties to the Omnibus Agreement entered into as of
July 13, 2004, as amended as of the date hereof (the “
Omnibus Agreement ”).
2. The Omnibus Agreement
restricts the Holly Entities from engaging in any Restricted
Business (as such term is defined in the Omnibus Agreement) to the
extent provided in Article II thereof.
3. Holly has entered into a
Memorandum of Understanding dated June 26, 2007 with Sinclair
Transportation Company (“ Sinclair ”) relating
to the facilities and services required to initially transport
62,000 barrels per day of refined petroleum products from Salt Lake
City, Utah to Las Vegas, Nevada, including a 12-inch diameter or
greater pipeline with an ANSI 600# pressure rating and a length of
approximately 400 miles, along with terminals in or near the Cedar
City area of Southern Utah and Las Vegas, Nevada (the “
UNEV Project ”).
4. The Parties desire by their
execution of this Agreement to evidence their agreement that the
provisions of Article II of the Omnibus Agreement shall not
apply to the UNEV Project and are hereby waived to such extent and
in lieu thereof HEP-Operating shall have an option to purchase the
Holly UNEV Interests on the terms and conditions set forth
herein.
5. The Parties desire that the
exercise price for the option shall be determined based on the
principle that HEP-Operating shall acquire the Holly UNEV Interests
in exchange for a cash payment equal to the Option Purchase
Price.
In consideration of the premises and
the covenants, conditions, and agreements contained herein, and for
other good and valuable consideration, the receipt and sufficiency
of which are hereby acknowledged, the Parties hereto hereby agree
as follows:
ARTICLE I
The Option
1.1 Grant of
Option . Subject to the terms and conditions hereof, Holly
UNEV hereby grants to HEP-Operating an irrevocable option (the
“ Option ”) to purchase all of the Holly UNEV
Interests in the manner set forth below at a purchase price equal
to the Option Purchase Price plus or minus the Closing Adjustment
Amount payable in immediately available funds; provided ,
however , that at the election of Holly UNEV made at any
time prior to 5:00 p.m. Central time on the third business day
prior to the Closing (as defined below), up to five percent of the
Option Purchase Price shall be payable in Common Units valued based
on the average closing price for the five trading days ending on
the date immediately prior to the Closing (as defined below).
1.2 Exercise of
Option . The Option may be exercised by HEP-Operating, in
whole but not in part, at any time after the Project Completion
Date and on or before 5:00 p.m., Central time, on the Expiration
Date. In order to exercise the Option, HEP-Operating must send a
written notice (an “ Exercise Notice ”) to Holly
UNEV. Unless otherwise mutually agreed in writing by HEP-Operating
and Holly UNEV, the closing (the “ Closing ”) of
the exercise of the Option will take place on the first day of the
month following the month in which the Exercise Notice is delivered
(the “ Closing Date ”); provided ,
however , that if there are less than five business days
from the date the Exercise Notice is delivered until the first day
of the month following the month in which the Exercise Notice is
delivered, the Closing Date shall be the first day of the month
that is the second month following the month in which the Exercise
Notice is delivered. Upon receipt of an Exercise Notice, Holly UNEV
will be obligated to deliver the Holly UNEV Interests in accordance
with Section 1.3 of this Agreement, HEP-Operating will
be obligated to deliver the Option Purchase Price on the Closing
Date (or if the Closing Date falls on a day that is not a business
day, the business day immediately prior to the Closing Date) and
HEP-Operating or Holly UNEV will be obligated to deliver the
Closing Adjustment Amount in accordance with
Section 1.6 if such amount is positive or negative,
respectively. The Closing shall occur at the offices of Vinson
& Elkins L.L.P., 3700 Trammell Crow Center, 2001 Ross Avenue,
Dallas, Texas, unless another place is mutually agreed to in
writing by HEP-Operating and Holly UNEV.
1.3 Actions on the
Closing Date . On the Closing Date, Holly UNEV shall cause
the Holly UNEV Interests to be transferred to HEP-Operating free
and clear of all liens, claims, encumbrances and security interests
of any nature whatsoever against delivery of the Option Purchase
Price in immediately available funds.
1.4 Operations Amount
Estimates . Holly UNEV shall (1) no later than five
business days after the delivery of the Exercise Notice or the
Termination Option Exercise Notice, deliver to HEP-Operating an
estimated income statement and balance sheet of UNEV Pipeline for
the period commencing on the Project Completion Date through
11:59 p.m. on the date immediately prior to the Closing Date
or Termination Option Closing (either such time, the “
Effective Time ”) and as of the Effective Time,
respectively, together with a certificate containing a good faith
estimate of the Operations Amount calculated from such estimated
income statement and balance sheet, and (2) no earlier than
two days prior to the Closing or the Termination Option Closing,
deliver to HEP-Operating an estimated income statement and balance
sheet of UNEV
- 2 -
Pipeline
for the period commencing on the Project Completion Date through
the Effective Time and as of the Effective Time, respectively
(collectively, the “ Closing Financial Statements
”), together with a certificate containing a good faith
estimate of the Operations Amount calculated from the Closing
Financial Statements (the “ Estimated Closing Operations
Amount ”) (which shall be estimated prior to the
application of any payments to be made under
Section 1.2 or Section 3.6(c) ). The
Closing Financial Statements shall be prepared in accordance with
this Agreement and GAAP.
1.5 Final Operations
Amount Determination .
(a) As promptly as practicable after
the Closing or the Termination Option Closing (but in no event
later than 45 days after the Closing or the Termination Option
Closing), HEP-Operating shall deliver to Holly UNEV an income
statement and balance sheet of UNEV Pipeline for the period
commencing on the Project Completion Date through the Effective
Time and as of the Effective Time, respectively (the “
Final Closing Financial Statements ”), together with a
certificate stating the Operations Amount calculated from the Final
Closing Financial Statements (the “ Closing Operations
Amount ”). The Final Closing Financial Statements shall
be prepared in accordance with this Agreement and GAAP. Following
the delivery of the Final Closing Financial Statements to Holly
UNEV, HEP-Operating shall afford Holly UNEV and its representatives
the opportunity to review the Final Closing Financial Statements,
and such supporting schedules, analyses, workpapers and other
underlying records or documentation as are reasonably necessary and
appropriate. HEP-Operating shall, cooperate fully and promptly with
Holly UNEV and its representatives in such examination with respect
to all reasonable requests related thereto, including providing
answers to questions asked by Holly UNEV and its representatives,
and HEP-Operating shall promptly make available to Holly UNEV and
its representatives any records under HEP-Operating’s
reasonable control that are reasonably requested by Holly UNEV and
its representatives.
(b) If within 45 days following
delivery of the Final Closing Financial Statements to Holly UNEV,
Holly UNEV has not delivered to HEP-Operating written notice (the
“ Objection Notice ”) of its objections to the
Closing Operations Amount certified by HEP–Operating (such
Objection Notice must contain a statement describing in reasonable
detail the basis of such objections and the amounts so disputed),
then the Closing Operations Amount as calculated from such Final
Closing Financial Statements shall be deemed final and conclusive
and shall be “Final Operations Amount,” and each of the
parties hereto agrees that such amounts shall thereafter not be
subject to any appeal or further challenge hereunder or otherwise.
If Holly UNEV delivers the Objection Notice within such 45-day
period, then HEP-Operating and Holly UNEV shall submit the
objections set forth in the Objection Notice to binding arbitration
in accordance with Section 8.11 and “Final
Operations Amount” will be determined pursuant to binding
arbitration.
1.6 Adjustment
Payment . If the Final Operations Amount as determined
pursuant to Section 1.5 would result in a (i) positive
Closing Adjustment Amount, then HEP-Operating will promptly pay an
amount in cash to Holly UNEV, in immediately available funds, equal
to such
- 3 -
excess,
or (ii) negative Closing Adjustment Amount, then Holly UNEV
shall promptly pay an amount in cash to HEP-Operating, in
immediately available funds, equal to such shortfall.
1.7
Construction . The parties hereto covenant and agree
that if any provision of Article I of this Agreement
requires an amount or calculation to be “determined in
accordance with this Agreement and GAAP” (or words of similar
import), then to the extent that the terms of any provision of
Article I of this Agreement conflict with, or are
inconsistent with, GAAP in connection with such determination, the
terms of Article I of this Agreement shall
control.
ARTICLE II
Representations and Warranties
2.1 Representations and
Warranties of Holly UNEV .
Holly
UNEV hereby represents and warrants to HEP-Operating that:
(a) Holly UNEV has all necessary
power and authority to enter into this Agreement and to sell,
assign, transfer and deliver to HEP-Operating, pursuant to the
terms and conditions of this Agreement, the Holly UNEV
Interests;
(b) Holly UNEV owns beneficially and
of record all of the Holly UNEV Interests free and clear of all
liens, claims, encumbrances and security interests of any nature
whatsoever. Upon purchase of the Holly UNEV Interests pursuant to
this Agreement, HEP-Operating shall receive good and marketable
title to the Holly UNEV Interests free and clear of all liens,
claims, encumbrances and security interests of any nature
whatsoever other than those created by or on behalf of the HEP
Parties; and
(c) This Agreement is a legal, valid
and binding agreement of Holly UNEV enforceable against Holly UNEV
in accordance with its terms, except as enforcement may be limited
by bankruptcy, insolvency, moratorium or other similar laws
relating to creditors’ rights generally and except that the
availability of equitable remedies, including specific performance,
is subject to the discretion of the court before which any
proceeding therefor may be brought.
2.2 Representations and
Warranties of the HEP Parties .
The HEP
Parties hereby represent and warrant to Holly UNEV that:
(a) HEP-Operating has all necessary
power and authority to enter into this Agreement and prior to the
sending of the Exercise Notice or the Termination Option Exercise
Notice will have all necessary power and authority to buy the Holly
UNEV Interests from Holly UNEV pursuant to the terms and conditions
of this Agreement; and
(b) This Agreement is a legal, valid
and binding agreement of the HEP Parties enforceable against them
in accordance with its terms, except as enforcement may be limited
by bankruptcy, insolvency, moratorium or other similar laws
relating to creditors’ rights generally and except that the
availability of equitable remedies, including specific
- 4 -
performance, is
subject to the discretion of the court before which any proceeding
therefor may be brought.
ARTICLE III
Covenants
Unless otherwise indicated, each of
the covenants contained in Article III shall terminate
and be of no further force or effect at the Closing or the
Termination Option Closing, as applicable.
3.1 Transfer of Holly
UNEV Interests . On and after the date hereof and until the
earliest of the (i) Closing, (ii) Termination Option
Closing or (iii) termination of this Agreement pursuant to
Section 5.1 , the Holly Entities may transfer Holly
UNEV Interests only if immediately following such transfer, the
Holly UNEV Share is at least 75%, unless such transfer is made
pursuant to the exercise of the Option or the Termination
Option.
3.2 Conduct of the
Project.
(a) Holly UNEV shall use commercially
reasonable efforts to have HEP-Operating designated as the initial
operator of the UNEV Project commencing on or before the Project
Completion Date, subject to the terms of any applicable operating
agreement and any required consent of Sinclair;
(b) From and after the delivery of an
Exercise Notice pursuant to Section 1.2 , Holly UNEV
shall, to the extent within its control, cause UNEV Pipeline to
continue to maintain, operate, and administer the completed UNEV
Project in a good and workmanlike manner, consistent with industry
standards and the good routine operation of the completed UNEV
Project in material compliance with all Applicable Laws except to
the extent caused by actions taken or omitted by HEP-Operating as
the operator of the UNEV Project;
(c) Holly UNEV shall cause UNEV
Pipeline to maintain , in accordance with GAAP, financial records
and books of account with respect to the UNEV Project, including
all expenditures incurred in performing the UNEV Project, that
accurately reflect the transactions in the UNEV Project, and
maintain proper and adequate system of internal accounting controls
that provide reasonable assurance that transactions are accurately
recorded in all material respects; and
(d) Pursuant to the Project
Management Agreement to be executed concurrently with this
Agreement by Holly UNEV and UNEV Pipeline (the “ Project
Management Agreement ”), Holly UNEV shall invoice UNEV
Pipeline on a monthly basis for Holly UNEV’s services, which
services include, without limitation, (i) right of way
services that include a charge for indirect costs incurred by Holly
UNEV of 10% of the cost of right-of-way services, (ii)
pre-construction services that include a charge for indirect costs
incurred by Holly UNEV of 10% of the cost of the pre-construction
services, and (iii) construction management services for which
Holly UNEV is paid $75,000 per month. All employee costs relating
to the UNEV Project that are incurred by
- 5 -
Holly UNEV are
intended to be covered by the fees paid under the Project
Management Agreement.
3.3 Consultation and
Cooperation. Ninety (90) days prior to the estimated
Project Completion Date through the Expiration Date:
(a) Holly UNEV shall provide
HEP-Operating the right to examine and make copies of the Records
during normal business hours, upon reasonable advance notice to
Holly UNEV, and in a manner so as not to unreasonably interfere
with the normal business operations of UNEV Pipeline. Such right
may be exercised through any agent or employee of HEP-Operating
designated in writing by it, or by an independent accountant or
attorney so designated. HEP-Operating shall bear all actual
out-of-pocket third person expenses incurred in connection with any
such examination or copying. Holly UNEV shall make available to
HEP-Operating and its financing sources and other advisors, upon
reasonable advance notice to Holly UNEV, during normal business
hours, personnel of Holly UNEV who are knowledgeable with respect
to the UNEV Project in order that HEP-Operating may make such
diligence investigation as HEP-Operating reasonably considers
desirable for any purpose that relates to the transactions
contemplated by this Agreement, including, but not limited to,
HEP-Operating’s efforts to obtain financing for the Option
Purchase Price or the Termination Option Purchase Price, as
applicable. Any information obtained by HEP-Operating, its
employees, representatives, consultants, attorneys, agents, and its
financing sources and other advisors under this Agreement
(including, but not limited to, this Section 3.3(a) and
Section 3.3(c) ) shall be maintained as confidential.
Notwithstanding the foregoing, Holly UNEV shall not be required to,
or required to cause UNEV Pipeline or any of their Affiliates to,
grant access or furnish information to HEP-Operating or any of its
agents or employees if such access or the furnishing of such
information is prohibited by Applicable Law or an existing
contract; provided , however , that Holly UNEV shall
use commercially reasonable efforts to cause such access right to
be granted to HEP-Operating and its representatives, but neither
Holly UNEV, UNEV Pipeline nor any of their Affiliates shall be
obligated to pay money to any third party for such consent or
waiver;
(b) Holly UNEV will cause UNEV
Pipeline to grant to HEP-Operating the right, exercisable at
HEP-Operating’s risk and expense, to make such surveys, tests
and inspections of the UNEV Project as HEP-Operating may deem
desirable, so long as such surveys, tests or inspections do not
damage the UNEV Project or interfere in any material respect with
the activities of UNEV Pipeline thereon and so long as
HEP-Operating has furnished Holly UNEV and UNEV Pipeline with
evidence that adequate liability insurance is in full force and
effect;
(c) Holly UNEV shall use its
reasonable commercial efforts to provide to HEP-Operating and any
of its financing sources all cooperation reasonably requested by
HEP-Operating or such financing sources that is reasonably
necessary or customary in connection with the financing of the
Option Purchase Price or the Termination Option Purchase Price, as
applicable (provided that such requested cooperation does not
unreasonably interfere with the business or operations of Holly
UNEV or UNEV
- 6 -
Pipeline),
including furnishing HEP-Operating, within a commercially
reasonable amount of time, with operational, financial and other
pertinent information as may be reasonably requested by
HEP-Operating in connection with the financing; provided
that neither Holly UNEV nor UNEV Pipeline shall be required to pay
any commitment or other similar fee or incur any other cost or
expense in connection with such financing; provided ,
further , that, neither Holly UNEV nor UNEV Pipeline shall
be required to incur any liability in connection with any such
financing. HEP-Operating shall, promptly upon request by Holly
UNEV, reimburse Holly UNEV for all reasonable documented out of
pocket costs and expenses incurred by Holly UNEV and UNEV Pipeline
in connection with such cooperation and shall indemnify and hold
harmless Holly UNEV and UNEV Pipeline and their respective
representatives from and against any and all liabilities, losses,
damages, claims, expenses, interest, judgments and penalties
suffered or incurred by them in connection with the arrangement of
any such financing and any information utilized in connection
therewith (other than information provided by Holly UNEV in
accordance with the terms hereof); and
(d) Holly UNEV will, within a
commercially reasonable amount of time, provide to HEP-Operating
true, correct and complete copies of (i) each of the
Transaction Agreements, and (ii) the annual budgets related to
the UNEV Project and unaudited annual and quarterly financial
statements of UNEV Pipeline.
3.4 Additional
Covenants .
(a) In connection with the UNEV
Project, Holly UNEV may make such Material Modifications as Holly
UNEV deems appropriate or necessary and in furtherance of, and
consistent with, the overall intent and purpose of the UNEV
Project. Holly UNEV shall notify HEP-Operating in writing promptly
of any contemplated Material Modifications and Holly UNEV shall
consult and discuss such Material Modifications with HEP-Operating
to the extent reasonably requested by HEP-Operating. After such
consultation and discussion, Holly UNEV shall be entitled, in its
sole discretion, to cause UNEV Pipeline to approve and implement
any Material Modification;
(b) Holly UNEV shall keep
HEP-Operating reasonably informed as to the status and progress of
the UNEV Project and the operations of UNEV Pipeline.
(c) Holly UNEV shall promptly notify
HEP-Operating in writing if Holly UNEV determines that there will
be a material deviation in the Project Schedule that would result
in (i) Holly UNEV failing to substantially complete a material
milestone specified in the Project Schedule by the date set forth
therefor in the Project Schedule or (ii) the Project
Completion Date being materially delayed from the date set forth in
the Project Schedule.
(d) Holly UNEV shall promptly notify
HEP-Operating in writing if Holly UNEV determines that the Total
Investment will be materially higher than the budgeted amount of
$225,000,000.00.
- 7 -
(e) Within 10 days following the
Project Completion Date, Holly UNEV will deliver to HEP-Operating a
reasonably detailed statement which calculates the Option Purchase
Price as of the Project Completion Date, and within 30 days
following the Project Completion Date, Holly UNEV will deliver to
HEP-Operating an unaudited balance sheet of UNEV Pipeline as of the
Project Completion Date and prepared in accordance with GAAP.
3.5 Limitation on the
Activities of UNEV Pipeline. With respect to the activities
of UNEV Pipeline, Holly UNEV will not consent to UNEV Pipeline
engaging in any activities other than the following: (i) the
design, construction, development, maintenance, ownership and,
after the Project Completion Date, operation of the UNEV Project,
and (ii) engaging in any other business or activity that now
or hereafter may be necessary, incidental, proper, advisable, or
convenient to accomplish the foregoing purposes, whether directly
or indirectly through the ownership and management of one or more
Subsidiaries of UNEV Pipeline.
3.6 Termination of the
Project.
(a) Notwithstanding any other
provision of this Agreement, Holly UNEV reserves the right, without
any liability or obligation to HEP-Operating whatsoever, to cause
UNEV Pipeline to terminate the UNEV Project at any time and for any
reason if Holly UNEV determines in its sole discretion that
continuation of the UNEV Project is not in Holly UNEV’s best
interest. If Holly UNEV decides to cause UNEV Pipeline to terminate
the UNEV Project, it shall send prompt written notice (the “
Termination Notice ”) to HEP-Operating of such
decision;
(b) Upon receipt of the Termination
Notice and subject to the terms and conditions hereof,
HEP-Operating shall have an irrevocable option (the “
Termination Option ”) to purchase all of the Holly
UNEV Interests in the manner set forth below at a purchase price
equal to the Termination Option Purchase Price plus or minus the
Closing Adjustment Amount payable in immediately available funds;
provided , however , that at the election of Holly
UNEV made at any time prior to 5:00 p.m. Central time on the third
business day prior to the Termination Option Closing (as defined
below), up to five percent of the Termination Option Purchase Price
shall be payable in Common Units valued based on the average
closing price for the five trading days ending on the date
immediately prior to the Termination Option Closing (as defined
below);
(c) The Termination Option may be
exercised by HEP-Operating, in whole but not in part, on or before
5:00 p.m., Central time, on the 30th day after the date of
HEP-Operating’s receipt of the Termination Notice (the
“ Termination Option Expiration Date ”). In
order to exercise the Termination Option, HEP-Operating must send a
written notice (a “ Termination Option Exercise Notice
”) to Holly UNEV. Unless otherwise mutually agreed in writing
by HEP-Operating and Holly UNEV, the closing (the “
Termination Option Closing ”) of the exercise of the
Termination Option will take place on the first day of the month
following the month in which the Termination Option Exercise Notice
is delivered (the “ Termination Option Closing Date
”); provided , however , that if there are less
than five business days from the date the Termination Option
Exercise Notice is delivered until the first day of the month
- 8 -
following the
month in which the Termination Option Exercise Notice is delivered,
the Termination Option Closing Date shall be the first day of the
month that is the second month following the month in which the
Termination Option Exercise Notice is delivered. Upon receipt of a
Termination Option Exercise Noti
|