|
Exhibit
10.1
CONSTRUCTION LOAN
AGREEMENT
for a loan in the amount
of
$148,864,335
MADE BY AND
BETWEEN
TARANTULA VENTURES
LLC,
a Delaware limited
liability company,
As Borrower
AND
KEYBANK NATIONAL
ASSOCIATION,
a national banking
association,
127 Public
Square,
Cleveland, Ohio
44114
as a Lender and as
Administrative Agent
AND
KEYBANC CAPITAL
MARKETS
as sole lead arranger and
book manager
Dated as of December 20,
2007
TABLE OF
CONTENTS
|
|
|
|
|
|
|
| |
|
|
|
|
|
Page |
|
ARTICLE 1
|
|
|
|
INCORPORATION OF RECITALS AND
EXHIBITS |
|
1 |
|
|
|
|
|
1.1
|
|
|
|
Incorporation of Recitals |
|
1 |
|
|
|
|
|
1.2
|
|
|
|
Incorporation of Exhibits |
|
1 |
|
|
|
|
|
ARTICLE 2
|
|
|
|
DEFINITIONS |
|
2 |
|
|
|
|
|
2.1
|
|
|
|
Defined
Terms |
|
2 |
|
|
|
|
|
2.2
|
|
|
|
Other
Definitional Provisions |
|
16 |
|
|
|
|
|
ARTICLE 3
|
|
|
|
BORROWER’S REPRESENTATIONS AND
WARRANTIES |
|
16 |
|
|
|
|
|
3.1
|
|
|
|
Representations and Warranties |
|
16 |
|
|
|
|
|
3.2
|
|
|
|
Survival
of Representations and Warranties |
|
22 |
|
|
|
|
|
ARTICLE 4
|
|
|
|
LOAN AND LOAN DOCUMENTS |
|
22 |
|
|
|
|
|
4.1
|
|
|
|
Agreement
to Borrow and Lend; Lender’s Obligation to
Disburse |
|
22 |
|
|
|
|
|
4.2
|
|
|
|
Loan
Documents |
|
23 |
|
|
|
|
|
4.3
|
|
|
|
Term of
the Loan |
|
24 |
|
|
|
|
|
4.4
|
|
|
|
Prepayments |
|
24 |
|
|
|
|
|
4.5
|
|
|
|
Required
Principal Payments |
|
25 |
|
|
|
|
|
4.6
|
|
|
|
Late
Charge |
|
25 |
|
|
|
|
|
4.7
|
|
|
|
Funds for
Payment |
|
25 |
|
|
|
|
|
ARTICLE 5
|
|
|
|
INTEREST |
|
26 |
|
|
|
|
|
5.1
|
|
|
|
Interest
Rate |
|
26 |
|
|
|
|
|
5.2
|
|
|
|
[Intentionally Omitted.] |
|
28 |
|
|
|
|
|
ARTICLE 6
|
|
|
|
COSTS OF MAINTAINING LOAN |
|
28 |
|
|
|
|
|
6.1
|
|
|
|
Increased
Costs and Capital Adequacy |
|
28 |
|
|
|
|
|
6.2
|
|
|
|
Borrower
Withholding |
|
29 |
|
|
|
|
|
ARTICLE 7
|
|
|
|
LOAN EXPENSE AND ADVANCES |
|
30 |
|
|
|
|
|
7.1
|
|
|
|
Loan and
Administration Expenses |
|
30 |
|
|
|
|
|
7.2
|
|
|
|
Fees |
|
30 |
|
|
|
|
|
7.3
|
|
|
|
[Intentionally Omitted.] |
|
30 |
|
|
|
|
|
7.4
|
|
|
|
Agent’s Attorneys’ Fees and
Disbursements |
|
30 |
|
|
|
|
|
7.5
|
|
|
|
Time of
Payment of Fees and Expenses |
|
31 |
|
|
|
|
|
7.6
|
|
|
|
Expenses
and Advances Secured by Loan Documents |
|
31 |
|
|
|
|
|
7.7
|
|
|
|
Right of
Lender to Make Advances to Cure Borrower’s
Defaults |
|
31 |
i
TABLE OF
CONTENTS
(continued)
|
|
|
|
|
|
|
| |
|
|
|
|
|
Page |
|
ARTICLE 8
|
|
|
|
NON-CONSTRUCTION REQUIREMENTS PRECEDENT
TO THE OPENING OF THE LOAN |
|
31 |
|
|
|
|
|
8.1
|
|
|
|
Non-Construction Conditions Precedent |
|
31 |
|
|
|
|
|
ARTICLE 9
|
|
|
|
CONSTRUCTION REQUIREMENTS PRECEDENT TO THE OPENING OF THE
LOAN |
|
34 |
|
|
|
|
|
9.1
|
|
|
|
Required
Construction Documents |
|
34 |
|
|
|
|
|
ARTICLE 10
|
|
|
|
BUDGET AND CONTINGENCY FUND |
|
35 |
|
|
|
|
|
10.1
|
|
|
|
Budget |
|
35 |
|
|
|
|
|
10.2
|
|
|
|
Budget
Line Items |
|
36 |
|
|
|
|
|
10.3
|
|
|
|
Contingency Fund |
|
36 |
|
|
|
|
|
10.4
|
|
|
|
Optional
Method for Payment of Interest |
|
36 |
|
|
|
|
|
ARTICLE 11
|
|
|
|
SUFFICIENCY OF LOAN |
|
37 |
|
|
|
|
|
11.1
|
|
|
|
Loan In
Balance |
|
37 |
|
|
|
|
|
ARTICLE 12
|
|
|
|
CONSTRUCTION PAYOUT
REQUIREMENTS |
|
37 |
|
|
|
|
|
12.1
|
|
|
|
Applicability of Sections |
|
37 |
|
|
|
|
|
12.2
|
|
|
|
Monthly
Payouts |
|
37 |
|
|
|
|
|
12.3
|
|
|
|
Documents
to be Furnished for Each Disbursement |
|
38 |
|
|
|
|
|
12.4
|
|
|
|
Retainages. |
|
39 |
|
|
|
|
|
12.5
|
|
|
|
Disbursements for Materials Stored On-Site |
|
39 |
|
|
|
|
|
12.6
|
|
|
|
Disbursements for Offsite Materials |
|
40 |
|
|
|
|
|
12.7
|
|
|
|
Intentionally Omitted |
|
40 |
|
|
|
|
|
ARTICLE 13
|
|
|
|
FINAL DISBURSEMENT FOR
CONSTRUCTION |
|
40 |
|
|
|
|
|
13.1
|
|
|
|
Final
Disbursement for Construction |
|
40 |
|
|
|
|
|
ARTICLE 14
|
|
|
|
RESERVED |
|
41 |
|
|
|
|
|
ARTICLE 15
|
|
|
|
OTHER COVENANTS |
|
41 |
|
|
|
|
|
15.1
|
|
|
|
Borrower
further covenants and agrees as follows: |
|
41 |
|
|
|
|
|
15.2
|
|
|
|
Authorized Representative |
|
51 |
|
|
|
|
|
ARTICLE 16
|
|
|
|
CASUALTIES AND CONDEMNATION |
|
52 |
|
|
|
|
|
16.1
|
|
|
|
Agent’s Election to Apply Proceeds on
Indebtedness |
|
52 |
|
|
|
|
|
16.2
|
|
|
|
Borrower’s Obligation to Rebuild and Use of Proceeds
Therefor |
|
53 |
|
|
|
|
|
ARTICLE 17
|
|
|
|
ASSIGNMENTS BY LENDER AND
BORROWER |
|
53 |
|
|
|
|
|
17.1
|
|
|
|
Prohibition of Assignments and Transfers by
Borrower |
|
53 |
ii
TABLE OF
CONTENTS
(continued)
|
|
|
|
|
|
|
| |
|
|
|
|
|
Page |
|
17.2
|
|
|
|
Prohibition of Transfers in Violation of ERISA |
|
53 |
|
|
|
|
|
17.3
|
|
|
|
Successors and Assigns |
|
54 |
|
|
|
|
|
ARTICLE 18
|
|
|
|
TIME OF THE ESSENCE |
|
54 |
|
|
|
|
|
18.1
|
|
|
|
Time is
of the Essence |
|
54 |
|
|
|
|
|
ARTICLE 19
|
|
|
|
EVENTS OF DEFAULT |
|
54 |
|
|
|
|
|
ARTICLE 20
|
|
|
|
LENDER’S REMEDIES IN EVENT OF
DEFAULT |
|
57 |
|
|
|
|
|
20.1
|
|
|
|
Remedies
Conferred Upon Lender |
|
57 |
|
|
|
|
|
ARTICLE 21
|
|
|
|
GENERAL PROVISIONS |
|
58 |
|
|
|
|
|
21.1
|
|
|
|
Captions |
|
58 |
|
|
|
|
|
21.2
|
|
|
|
Modification; Waiver |
|
58 |
|
|
|
|
|
21.3
|
|
|
|
Governing
Law |
|
58 |
|
|
|
|
|
21.4
|
|
|
|
Acquiescence Not to Constitute Waiver of Lender’s
Requirements |
|
58 |
|
|
|
|
|
21.5
|
|
|
|
Disclaimer by Lender |
|
58 |
|
|
|
|
|
21.6
|
|
|
|
Partial
Invalidity; Severability |
|
59 |
|
|
|
|
|
21.7
|
|
|
|
Definitions Include Amendments |
|
59 |
|
|
|
|
|
21.8
|
|
|
|
Execution
in Counterparts |
|
60 |
|
|
|
|
|
21.9
|
|
|
|
Entire
Agreement |
|
60 |
|
|
|
|
|
21.10
|
|
|
|
Waiver of
Damages |
|
60 |
|
|
|
|
|
21.11
|
|
|
|
Claims
Against Lender |
|
60 |
|
|
|
|
|
21.12
|
|
|
|
Jurisdiction |
|
60 |
|
|
|
|
|
21.13
|
|
|
|
Set-Offs |
|
61 |
|
|
|
|
|
ARTICLE 22
|
|
|
|
NOTICES |
|
61 |
|
|
|
|
|
ARTICLE 23
|
|
|
|
WAIVER OF JURY TRIAL |
|
62 |
|
|
|
|
|
ARTICLE 24
|
|
|
|
ASSIGNMENTS AND
PARTICIPATIONS |
|
63 |
|
|
|
|
|
24.1
|
|
|
|
Assignments and Participations |
|
63 |
|
|
|
|
|
24.2
|
|
|
|
Several
Liability |
|
66 |
|
|
|
|
|
ARTICLE 25
|
|
|
|
AGENT |
|
66 |
|
|
|
|
|
25.1
|
|
|
|
Appointment |
|
66 |
|
|
|
|
|
25.2
|
|
|
|
Reliance
on Agent |
|
67 |
|
|
|
|
|
25.3
|
|
|
|
Powers |
|
67 |
|
|
|
|
|
25.4
|
|
|
|
Disbursements |
|
67 |
iii
TABLE OF
CONTENTS
(continued)
|
|
|
|
|
|
|
| |
|
|
|
|
|
Page |
|
25.5
|
|
|
|
Distribution and Apportionment of Payments |
|
68 |
|
|
|
|
|
25.6
|
|
|
|
Consents
and Approvals |
|
70 |
|
|
|
|
|
25.7
|
|
|
|
Agency
Provisions Relating to Collateral |
|
72 |
|
|
|
|
|
25.8
|
|
|
|
Lender
Actions Against Borrower or the Collateral |
|
73 |
|
|
|
|
|
25.9
|
|
|
|
Assignment and Participation |
|
73 |
|
|
|
|
|
25.10
|
|
|
|
Ratable
Sharing |
|
74 |
|
|
|
|
|
25.11
|
|
|
|
General
Immunity |
|
74 |
|
|
|
|
|
25.12
|
|
|
|
No
Responsibility for Loan, Recitals, etc |
|
74 |
|
|
|
|
|
25.13
|
|
|
|
Action on
Instructions of Lenders |
|
75 |
|
|
|
|
|
25.14
|
|
|
|
Employment of Agents and Counsel |
|
75 |
|
|
|
|
|
25.15
|
|
|
|
Reliance
on Documents; Counsel |
|
76 |
|
|
|
|
|
25.16
|
|
|
|
Agent’ Reimbursement and Indemnification |
|
76 |
|
|
|
|
|
25.17
|
|
|
|
Rights as
a Lender |
|
76 |
|
|
|
|
|
25.18
|
|
|
|
Lenders’ Credit Decisions |
|
77 |
|
|
|
|
|
25.19
|
|
|
|
Notice of
Events of Default |
|
77 |
|
|
|
|
|
25.20
|
|
|
|
Successor
Agent |
|
77 |
iv
LIST OF EXHIBITS TO LOAN
AGREEMENT
|
|
|
| Exhibit A |
|
Legal
Description of Land |
|
|
| Exhibit B |
|
Permitted
Exceptions |
|
|
| Exhibit C |
|
Form of
Note |
|
|
| Exhibit D |
|
Intentionally Omitted |
|
|
| Exhibit E |
|
LIBOR Notice
Election |
|
|
| Exhibit F |
|
Insurance
Requirements |
|
|
| Exhibit G |
|
Architect’s Certificate |
|
|
| Exhibit H |
|
Initial
Budget |
|
|
| Exhibit I |
|
Borrower’s Certificate |
|
|
| Exhibit J |
|
Soft and
Hard Cost Requisition Form |
|
|
| Exhibit K |
|
Engineer’s Certificate |
|
|
| Exhibit L |
|
Assignment
and Assumption Agreement |
|
|
| Exhibit M |
|
Patriot Act
and OFAC Transferee and Assignee Identifying Information
Form |
v
CONSTRUCTION LOAN
AGREEMENT
Project Commonly Known
as
“Data Center Facility,
CH1, Elk Grove Village, Illinois”
THIS CONSTRUCTION LOAN
AGREEMENT (“ Agreement ”) is made as of
December 20, 2007, by and among TARANTULA VENTURES LLC, a
Delaware limited liability company (“ Borrower
”), and KEYBANK NATIONAL ASSOCIATION, a national banking
association (“KeyBank”), its successors and assigns,
individually and as a lender and administrative agent (referred to
in such capacity as “Agent” in this Agreement), and
each of the undersigned lending institutions (KeyBank, as a lender,
and each such lending institution, and their respective successors
and assigns, referred to individually or collectively, as the
context shall infer, as the “Lender”).
WITNESSETH
:
RECITALS
A. Borrower is the owner in
fee simple of the land located in the Elk Grove Village, County of
Cook, State of Illinois, and is legally described in
Exhibit A attached hereto (the “ Land
”). Borrower proposes to construct on the Land the first
phase of a data center facility to consist when fully completed of
approximately 485,000 gross square feet and 211,140 raised square
feet with a critical load of 36.4 megawatts. The first phase will
consist of approximately 121,223 raised square feet with a critical
load of 18.2 megawatts. As of the date hereof, a substantial amount
of the construction of this first phase has been
completed.
B. Borrower has applied to
Lender for a loan in the amount of up to One Hundred Forty-Eight
Million Eight Hundred Sixty-Four Thousand Three Hundred Thirty-Five
and No/100 Dollars ($148,864,335.00) (the “ Loan
”) to reimburse Borrower for construction and development of
the Project, and Lender is willing to make the Loan on the terms
and conditions hereinafter set forth.
NOW, THEREFORE, in
consideration of the mutual covenants and agreements herein
contained, the parties hereto agree as follows:
ARTICLE 1
INCORPORATION OF RECITALS
AND EXHIBITS
| 1.1 |
Incorporation of Recitals . |
The foregoing preambles and
all other recitals set forth herein are made a part hereof by this
reference.
| 1.2 |
Incorporation of Exhibits . |
Exhibits A through M, to
this Agreement, attached hereto are incorporated in this Agreement
and expressly made a part hereof by this reference.
ARTICLE 2
DEFINITIONS
The following terms as used
herein shall have the following meanings:
Adjusted LIBOR Rate :
For any LIBOR Rate Interest Period, an interest rate per annum
equal to the sum of (A) the rate obtained by dividing
(x) the LIBOR Rate for such LIBOR Rate Interest Period by
(y) a percentage equal to one hundred percent
(100%) minus the Reserve Percentage for such LIBOR Rate
Interest Period and (B) the LIBOR Rate Margin.
Adjusted Base Rate : A
rate per annum equal to the greater of (a) the Prime Rate and
(b) one-half of one percent (0.5%) in excess of the Federal
Funds Effective Rate. Any change in the Adjusted Base Rate shall be
effective immediately from and after a change in the Adjusted Base
Rate (or the Federal Funds Effective Rate, as
applicable).
Affiliate . An
Affiliate, as applied to any Person, shall mean any other Person
directly or indirectly controlling, controlled by, or under common
control with, that Person. For purposes of this definition,
“control” (including, with correlative meanings, the
terms “controlling”, “controlled by” and
“under common control with”), as applied to any Person,
means (a) the possession, directly or indirectly, of the power
to vote ten percent (10%) or more of the stock, shares, voting
trust certificates, beneficial interest, partnership interests,
member interests or other interests having voting power for the
election of directors of such Person or otherwise to direct or
cause the direction of the management and policies of that Person,
whether through the ownership of voting securities or by contract
or otherwise, or (b) the ownership of (i) a general
partnership interest, (ii) a managing member’s or
manager’s interest in a limited liability company or
(iii) a limited partnership interest or preferred stock (or
other ownership interest) representing ten percent (10%) or
more of the outstanding limited partnership interests, preferred
stock or other ownership interests of such Person.
Agent’s Head
Office : The Agent’s head office located at 127 Public
Square, Cleveland, Ohio 44114-1306, or at such other location as
the Agent may designate from time to time by notice to the Borrower
and the Lenders.
Agent’s Special
Counsel : McKenna Long & Aldridge LLP or such other
counsel as selected by Agent.
Agreement : This
Construction Loan Agreement.
Applicable Rate : As
such term is defined in Section 5.1(a) .
Appraisal : An MAI
appraisal of the value of the Project, determined on a “going
concern” value basis, performed by an independent appraiser
with experience appraising data center properties selected by the
Agent who is not an employee of Guarantor or its Subsidiaries, the
Agent or a Lender, the form and substance of such appraisal and the
identity of the appraiser to be in compliance with the Financial
Institutions Reform, Recovery and Enforcement Act of 1989, as
amended, the rules and regulations adopted pursuant thereto and all
other regulatory laws and policies (both regulatory and internal)
applicable to the Lenders and otherwise acceptable to the
Agent.
2
Appraised Value : The
“going concern” value of the Project determined by the
most recent Appraisal of the Project, obtained pursuant to this
Agreement; subject, however, to such changes or adjustments to the
value determined thereby as may be required by the appraisal
department of the Agent in its good faith business judgment based
on criteria and factors generally used and considered by the Agent
in determining the value of similar properties.
Approved Lease : Any
Lease that meets the following criteria shall not require
Agent’s or Lenders’ prior written approval:
(i) the rental rate thereunder is at least ninety percent
(90%) of the rental rate in the Pro Forma Projection;
(ii) the lease term is for a minimum of five
(5) consecutive years; (iii) the Lease does not contain
any early termination rights in favor of Tenant other than those
contained in customary casualty and condemnation provisions;
(iv) the proposed Tenant has been operating and profitable for
a minimum of five (5) consecutive years, or such
Tenant’s long-term senior debt rating is rated at least BBB-
by S&P or the equivalent thereof by Moody’s; and
(v) the Lease is entered into on the Borrower’s standard
form lease, which has been approved by Agent, without any material
modifications.
Architect : Donnally
Vujcic Associates, L.L.C.
Architect’s
Certificate : A certificate in the form of
Exhibit G attached hereto executed by the Architect in
favor of Lender.
Assignment and
Assumption : An Assignment and Assumption Agreement in the form
of Exhibit L attached hereto and made a part
hereof.
Assignment of Rents :
An assignment of leases and rents made by Borrower in favor of
Agent assigning all leases, subleases and other agreements relating
to the use and occupancy of all or any portion of the Project, and
all present and future leases, rents, issues and profits
therefrom.
Authorized
Representative : Hossein Fateh or Lammot J. du Pont, or such
other Person as Borrower may designate in writing to Agent from
time to time.
Bankruptcy Code :
Title 11 of the United States Code entitled
“Bankruptcy” as now or hereafter in effect, or any
successor statute thereto or any other present or future bankruptcy
or insolvency statute.
Bond : A Performance
Bond and Labor and Material Payment Bond in a form approved by
Agent, with the Major Subcontractors, as the case may be, as
principal, with a surety company acceptable to Agent and licensed
to do business in the State, as surety, with a dual obligee rider
in favor of Agent.
Breakage Costs : The
cost to Lender of re-employing funds bearing or to bear interest at
an Adjusted LIBOR Rate, incurred (or expected to be incurred) in
connection with (i) any payment of any portion of the Loan
bearing interest at an Adjusted LIBOR Rate prior to the termination
of any applicable LIBOR Rate Interest Period, (ii) the
conversion of an Adjusted
3
LIBOR Rate to any other applicable
interest rate on a date other than the last day of the relevant
LIBOR Rate Interest Period, or (iii) the failure of Borrower
to draw down, on the first day of the applicable LIBOR Rate
Interest Period, any amount as to which Borrower has elected a
LIBOR Rate Option.
Budget : The budget
for the Project specifying all costs and expenses of every kind and
nature whatever to be incurred by Borrower in connection with the
Project prior to the Maturity Date.
Budget Line Item : As
such term is defined in Section 10.2 .
Business Day : A day
of the year on which banks are not required or authorized to close
in Cleveland, Ohio.
Change of Control . A
Change of Control shall exist upon the occurrence of any of the
following:
(a) Any Person (including a
Person’s Affiliates and associates) or group (as that term is
understood under Section 13(d) of the Securities Exchange Act
of 1934, as amended (the “Exchange Act”) and the rules
and regulations thereunder), other than Lammot du Pont and
Hossein Fateh and their respective controlled Affiliates, shall
have acquired beneficial ownership (within the meaning of Rule
13d-3 under the Exchange Act) of a percentage (based on voting
power, in the event different classes of stock or voting interests
shall have different voting powers) of the voting stock or voting
interests of REIT or Guarantor equal to at least twenty percent
(20%);
(b) As of any date a majority
of the Board of Directors or Trustees or similar body (the
“Board”) of REIT or Guarantor consists of individuals
who were not either (i) directors or trustees of REIT or
Guarantor as of the corresponding date of the previous year, or
(ii) selected or nominated to become directors or trustees by
the Board of REIT or Guarantor of which a majority consisted of
individuals described in clause (b)(i) above, or
(iii) selected or nominated to become directors or trustees by
the Board of REIT or Guarantor, which majority consisted of
individuals described in clause (b)(i) above and individuals
described in clause (b)(ii), above (excluding, in the case of both
clause (ii) and (iii) above, any individual whose initial
nomination for, or assumption of office as, a member of the Board
occurs as a result of an actual or threatened solicitation of
proxies or consents for the election or removal of one or more
directors or trustees by any Person or group other than a
solicitation for the election of one or more directors or trustees
by or on behalf of the Board); or
(c) the Borrower or Guarantor
consolidates with, is acquired by, or merges into or with any
Person (other than a merger permitted by §15.1(jj));
or
(d) REIT shall fail to own at
least thirty-three percent (33%) of the economic, voting and
beneficial interests in Guarantor, or shall fail to own such
interests free of any lien, encumbrance or other adverse claim;
or
4
(e) REIT shall fail to be the
sole general partner of Guarantor, shall fail to own such general
partnership interest in Guarantor free of any lien, encumbrance or
other adverse claim, or shall fail to control the management and
policies of Guarantor; or
(f) Guarantor fails to own
directly or indirectly, free of any lien, encumbrance or other
adverse claim, at least one hundred percent (100%) of the
economic, voting and beneficial interest of Borrower (except that
REIT may own up to one percent (1%) of Safari Ventures LLC);
or
(g) Any of Lammot du Pont and
Hossein Fateh shall cease to be senior management executives of the
REIT and a competent and experienced successor senior management
executive, as applicable, shall not be reasonably approved by the
Required Lenders within three (3) months of such
event.
Change Order : Any
request for changes in the Plans and Specifications (other than
minor field changes involving no extra cost).
Collateral . All of
(a) the property, rights and interests of the Borrower that
are or are intended to be subject to the security interests,
assignments, and mortgage liens created by the Security Documents,
including, without limitation, the Project, and (b) the
Guaranty.
Commitment : The
maximum amount each Lender has agreed to lend to Borrower as part
of the Loan (which amounts are set forth below the signature line
of each Lender), subject to modification by each Assignment and
Assumption.
Completion Conditions
: Delivery to Agent of the following items in form satisfactory to
the Agent:
(A) Required Permits .
Evidence that the Borrower has obtained all Required Permits from,
given all notices to, and taken all such other actions with respect
to, such Governmental Authority as may be required under applicable
laws and requirements for the permanent use and occupancy of the
Improvements for their intended uses, together with copies of all
such Required Permits;
(B) Approval by
Lender’s Consultant . Notification from the
Lender’s Consultant to the effect that the Improvements have
been completed in a good and workmanlike manner in accordance with
the Plans and Specifications;
(C) Certificate of the
Borrower’s Architect . Certificate of the
Borrower’s architect that the Improvements have been
completed in accordance with the Plans and Specifications and that
the Improvements comply with all applicable laws and requirements
and Governmental Approvals and are in all respects ready for use
and occupancy;
(D) Payment of Costs .
Evidence satisfactory to Agent that all sums due in connection with
the construction of the Improvements have been paid or discharged
in full (whether by bonding or otherwise) and that no party claims
or has a right to claim any statutory or common law lien arising
out of the construction of the Improvements for the supplying of
labor, material, equipment and/or services in connection
therewith;
5
(E) Final Lien Waivers
. Final lien waivers in such form as may be permitted by applicable
law to remove or dissolve any unfiled lien claims, or such other
form satisfactory to the Agent from the General Contractors, and
such laborers, suppliers, subcontractors and materialmen as may be
requested by the Agent, duly executed and notarized (or with
respect to any lien claims for which final lien waivers are not
provided, evidence satisfactory to Agent that such lien claims have
been discharged in full (whether by bonding or
otherwise));
(F) Title Endorsement
. An endorsement to the Title Policy fully removing any exception
for mechanics and materialman’s liens, whether filed or
unfiled.
(G) Power . The
Improvements shall have at least 18.2 megawatts of critical load
power available for use by Tenants.
Completion Date :
June 30, 2008, subject to extension pursuant to
Section 15.1(b) .
Consolidated : With
reference to any term defined herein, that term as applied to the
accounts of a Person and its Subsidiaries, determined on a
consolidated basis in accordance with GAAP.
Construction or
construction : The construction and equipping of the
Improvements in accordance with the Plans and Specifications, and
the installation of all personal property, fixtures and equipment
required for the operation of the Project.
Construction Schedule
: A schedule satisfactory to Lender and Lender’s Consultant,
establishing a timetable for completion of the Construction,
showing, on a monthly basis, the anticipated progress of the
Construction and also showing that the Improvements can be
completed on or before the Completion Date, as the same may be
modified or amended with the written approval of Agent.
Contingency Fund : A
Budget Line Item which shall represent an amount necessary to
provide reasonable assurances to Lender that additional funds are
available to be used if additional costs and expenses are incurred
or additional interest accrues on the Loan, or unanticipated events
or problems occur.
Control : As such term
is used with respect to any person or entity, including the
correlative meanings of the terms “controlled by” and
“under common control with”, shall mean the possession,
directly or indirectly, of the power to direct or cause the
direction of the management policies of such person or entity,
whether through the ownership of voting securities, by contract or
otherwise.
Debt Service Coverage
: With respect to a particular period, the ratio of (a) the
Net Operating Income of the Project to (b) the Total Annual
Debt Service.
Default or default :
Any event, circumstance or condition, which, if it were to continue
uncured, would, with notice or lapse of time or both, constitute an
Event of Default hereunder.
Defaulting Lender : As
such term is defined in Section 25.5(b) .
6
Default Rate : A rate
per annum equal to two percentage points (200 basis points) in
excess of the Applicable Rate, but not at any time in excess of the
highest rate permitted by law.
Deficiency Deposit :
As such term is defined in Section 11.1 .
Eligible Assignee :
(i) Any Lender; (ii) any commercial bank, savings bank,
savings and loan association or similar financial institution which
(A) has total assets of Five Billion Dollars ($5,000,000,000)
or more, (B) is “well capitalized” within the
meaning of such term under the regulations promulgated under the
auspices of the Federal Deposit Insurance Corporation Improvement
Act of 1991, (C) in the reasonable judgment of the Agent, is
engaged in the business of lending money and extending credit, and
buying loans or participations in loans under credit facilities
substantially similar to those extended under this Agreement, and
(D) in the reasonable judgment of the Agent, is operationally
and procedurally able to meet the obligations of a Lender hereunder
to the same degree as a commercial bank; (iii) any insurance
company in the business of writing insurance which (A) has
total assets of Five Billion Dollars ($5,000,000,000) or more
(B) is “best capitalized” within the meaning of
such term under the applicable regulations of the National
Association of Insurance Commissioners, and (C) meets the
requirements set forth in subclauses (C) and (D) of
clause (ii) above; and (iv) any other financial
institution having total assets of Five Billion Dollars
($5,000,000,000) (including a mutual fund or other fund under
management of any investment manager having under its management
total assets of Five Billion Dollars ($5,000,000,000) or more)
which meets the requirement set forth in subclauses (C) and
(D) of clause (ii) above; provided that each Eligible
Assignee must (w) be organized under the Laws of the United
States of America, any state thereof or the District of Columbia,
or, if a commercial bank, be organized under the Laws of the United
States of America, any state thereof or the District of Columbia,
the Cayman Islands or any country which is a member of the
Organization for Economic Cooperation and Development, or a
political subdivision of such a country, (x) act under the
Loan Documents through a branch, agency or funding office located
in the United States of America, (y) be exempt from
withholding of tax on interest and deliver the documents related
thereto pursuant to the Internal Revenue Code as in effect from
time to time and (z) not be the Borrower or an Affiliate of
the Borrower.
Engineer : EYP Mission
Critical Engineering.
Engineer’s
Certificate : A certificate in the form of
Exhibit K attached hereto executed by the Architect in
favor of Lender.
Environmental Engineer
: AEI Consultants or another firm of independent professional
engineers or other scientists generally recognized as expert in the
detection, analysis and remediation of Hazardous Substances and
related environmental matters and acceptable to the Agent in its
reasonable discretion.
Environmental
Indemnity : An environmental indemnity from the Borrower and
Guarantor, jointly and severally, indemnifying Agent and the
Lenders with regard to all matters related to Hazardous Substances
and other environmental matters.
7
Environmental
Proceedings : Any environmental proceedings, whether civil
(including actions by private parties), criminal, or administrative
proceedings, relating to the Project.
Environmental Report :
An environmental report prepared at Borrower’s expense by an
Environmental Engineer, dated not more than one year prior to the
date of this Agreement and addressed to Agent (or subject to
separate letter agreement permitting Agent to rely on such
environmental report).
Environmental Laws :
As defined in the Environmental Indemnity.
Equity Interests :
With respect to any Person, shares of capital stock of (or other
ownership or profit interests in) such Person, warrants, options or
other rights for the purchase or other acquisition from such Person
of shares of capital stock of (or other ownership or profit
interests in) such Person, securities convertible into or
exchangeable for shares of capital stock of (or other ownership or
profit interests in) such Person or warrants, rights or options for
the purchase or other acquisition from such Person of such shares
(or such other interests), and other ownership or profit interests
in such Person (including, without limitation, partnership, member
or trust interests therein), whether voting or nonvoting, and
whether or not such shares, warrants, options, rights or other
interests are authorized or otherwise existing as of any date of
determination.
ERISA : The Employee
Retirement Income Security Act of 1974, as amended, and the
regulations promulgated thereunder from time to time.
Event of Default : As
such term is defined in Article 19 .
Extended Maturity Date
: As such term is defined in Section 4.3 .
Extension Option : As
such term is defined in Section 4.3 .
Extension Term : The
period of time commencing on the day after the Initial Maturity
Date and ending on the Extended Maturity Date.
Federal Funds Effective
Rate : Shall mean, for any day, the rate per annum (rounded
upward to the nearest on one-hundredth of one percent (1/100 of
1%)) announced by the Federal Reserve Bank of New York on such day
as being the weighted average of the rates on overnight federal
funds transactions arranged by federal funds brokers on the
previous trading day, as computed and announced by such Federal
Reserve Bank in substantially the same manner as such Federal
Reserve Bank computes and announces the weighted average it refers
to as the “Federal Funds Effective Rate.”
FIRREA : The Financial
Institutions Reform, Recovery And Enforcement Act of 1989, as
amended from time to time.
Funds from Operations
: With respect to any Person for any period, an amount equal to the
Net Income (or Loss) of such Person for such period, computed in
accordance with GAAP, excluding losses from sales of property, plus
depreciation and amortization, and after adjustments for
unconsolidated partnerships and joint ventures. Adjustments for
unconsolidated partnerships and joint ventures will be recalculated
to reflect funds from operations on the same basis.
8
GAAP : Principles that
are (a) consistent with the principles promulgated or adopted
by the Financial Accounting Standards Board and its predecessors,
as in effect from time to time and (b) consistently applied
with past financial statements of the Person adopting the same
principles.
General Contract : The
general contract(s) between Borrower and General Contractor,
pertaining to the construction of all onsite and offsite
improvements for the Project.
General Contractor(s)
: Holder Construction Company.
Governmental Approvals
: Collectively, all consents, licenses, and permits and all other
authorizations or approvals required from any Governmental
Authority for the Construction in accordance with the Plans and
Specifications.
Governmental Authority
: Any federal, state, county or municipal government, or political
subdivision thereof, any governmental or quasi-governmental agency,
authority, board, bureau, commission, department, instrumentality,
or public body, or any court, administrative tribunal, or public
utility.
Gross Asset Value : As
defined in the Revolving Credit Agreement.
Guarantor : DuPont
Fabros Technology, L.P., a Maryland limited partnership.
Guaranty : A guaranty
of payment, performance and completion, executed by Guarantor and
pursuant to which the Guarantor guarantees the payment of the Notes
and the other amounts due under the Loan Documents, and the
lien-free and timely completion of the Project in accordance with
all provisions of this Agreement and Borrower’s obligation to
keep the Loan In Balance and to pay for all cost
overruns.
Hazardous Substances .
As defined in the Environmental Indemnity.
Improvements : The
improvements referred to in Recital A hereto and more
particularly described in the Plans and Specifications, and offsite
improvements and together with any existing improvements on the
Land not to be demolished.
In Balance or in
balance : As such term is defined in Article 11
.
Including or including
: Including but not limited to.
Indebtedness : As
defined in the Revolving Credit Agreement.
Indemnity and Guaranty
Agreement : The Indemnity and Guaranty Agreement dated of even
date herewith made by Guarantor in favor of the Agent and the
Lenders, as the same may be modified, amended or ratified, such
Indemnity and Guaranty Agreement to be in form and substance
satisfactory to the Agent.
9
Initial Maturity Date
: December 20, 2009, or such earlier date on which the Loan
shall become due and payable pursuant to the terms
hereof.
Internal Revenue Code
: The Internal Revenue Code of 1986, as amended from time to
time.
Interest Payment Date
: The first (1 st ) day of each calendar month during the term of the
Loan.
Land : As such term is
defined in Recital A .
Late Charge : As such
term is defined in Section 4.6 .
Laws : Collectively,
all federal, state and local laws, statutes, codes, ordinances,
orders, rules and regulations, including judicial opinions or
precedential authority in the applicable jurisdiction.
Leases : The
collective reference to all leases, subleases and occupancy
agreements affecting the Project or any part thereof now existing
or hereafter executed and all amendments, modifications or
supplements thereto approved in writing by Agent, or deemed
approved pursuant to Section 15.1(k), if such approval is
required.
Lender : As defined in
the opening paragraph of this Agreement. A reference to a Lender
shall include all Lenders unless the context clearly refers to a
single Lender.
Lender’s
Consultant : An independent consulting architect, inspector,
and/or engineer designated by Agent in Agent’s sole
discretion.
Lender Default
Obligation : As such term is defined in
Section 25.5(b) .
Lender Reply Period :
As such term is defined in Section 25.6 .
Lien : Any lien,
security interest or other charge or encumbrance of any kind, or
any other type of preferential arrangement, including, without
limitation, the lien or retained security title of a conditional
vendor and any easement, right of way or other encumbrance on title
to real property.
LIBOR Business Day : A
Business Day on which dealings in U.S. dollars are carried on in
the London Interbank Market.
LIBOR Rate : For any
LIBOR Rate Interest Period, the average rate (rounded upwards to
the nearest 1/16th) as shown in Reuters Screen LIBOR01 Page at
which deposits in U.S. dollars are offered by first class banks in
the London Interbank Market at approximately 11:00 a.m. (London
time) on the day that is two (2) LIBOR Business Days prior to
the first day of such LIBOR Rate Interest Period with a maturity
approximately equal to such LIBOR Rate Interest Period and in an
amount approximately equal to the amount to which such LIBOR Rate
Interest Period relates, adjusted for reserves and taxes if
required by future regulations. If such service no longer reports
such rate or Agent determines in good faith that the rate so
reported no longer accurately reflects the rate available to Lender
in the London Interbank Market, Agent may select a replacement
index.
10
LIBOR Rate Interest
Period : With respect to each amount bearing interest at a
LIBOR based rate, a period of one, two, three months or six months,
to the extent deposits with such maturities are available to Agent,
commencing on a LIBOR Business Day, as selected by Borrower
provided, however, that (i) any LIBOR Rate Interest Period
which would otherwise end on a day which is not a LIBOR Business
Day shall continue to and end on the next succeeding LIBOR Business
Day, unless the result would be that such LIBOR Rate Interest
Period would be extended to the next succeeding calendar month, in
which case such LIBOR Rate Interest Period shall end on the next
preceding LIBOR Business Day, (ii) any LIBOR Rate Interest
Period which begins on a day for which there is no numerically
corresponding date in the calendar month in which such LIBOR Rate
Interest Period would otherwise end shall instead end on the last
LIBOR Business Day of such calendar month, and (iii) Borrower
may not select a LIBOR Rate Interest Period which would end after
the Maturity Date.
LIBOR Rate Margin :
2.25 percent (225 basis points) per annum.
LIBOR Rate Option : As
defined in Section 5.1(b) .
Loan : As defined in
Recital B .
Loan Amount : The
maximum amount of the Loan as set forth in
Section 4.1(a) as reduced by principal payments made
from time to time.
Loan Documents : The
collective reference to this Agreement, the documents and
instruments listed in Section 4.2 , and all the other
documents and instruments entered into from time to time,
evidencing or securing the Loan or any obligation of payment
thereof or performance of Borrower’s or Guarantor’s
obligations in connection with the transaction contemplated
hereunder, each as amended.
Loan Opening Date :
The date of the first disbursement of proceeds of the
Loan.
Major Subcontractor :
Any subcontractor under a Major Subcontract.
Major Subcontracts :
All subcontracts between either General Contractor and any
subcontractors and material suppliers which provide for an
aggregate contract price equal to or greater than
$3,000,000.
Management Agreements
: Agreements, whether written or oral, providing for the management
of the Project. As of the Loan Opening Date, no Management
Agreement exists.
Material Adverse Change or
material adverse change : If, in Agent’s reasonable
discretion, the business operations or financial condition of the
Project, Borrower or Guarantor has changed in a manner which could
materially impair the value of Lender’s security for the
Loan, prevent timely repayment of the Loan or otherwise prevent the
applicable person or entity from timely performing any of its
material obligations under the Loan Documents.
11
Maturity Date : The
Initial Maturity Date, provided, if Borrower timely satisfies the
conditions to extend the term of the Loan pursuant to
Section 4.3(b) , then the Maturity Date shall be
extended to the Extended Maturity Date, or such earlier date on
which the Loan shall become due and payable pursuant to the terms
hereof.
Moody’s .
Moody’s Investor Service, Inc.
Mortgage : A mortgage
(or deed of trust), assignment of leases and rents, security
agreement and fixture filing, executed by Borrower for the benefit
of Agent and the Lenders securing this Agreement, the Notes, and
all obligations of Borrower in connection with the Loan, granting a
first priority lien on Borrower’s fee interest in the
Project, subject only to the Permitted Exceptions.
Net Income (or Loss) :
With respect to any Person (or any asset of any Person) for any
period, the net income (or loss) of such Person (or attributable to
such asset), determined in accordance with GAAP.
Net Operating Income :
As of any date of determination, an amount equal to the sum of
(i) the rents, common area reimbursements and other income for
the Project for such period received in the ordinary course of
business from Tenants (excluding pre-paid rents and revenues and
security deposits except to the extent applied in the satisfaction
of tenants’ obligations for rent) minus (b) all expenses
paid or accrued and related to the ownership, operation or
maintenance of the Project for such period, including, but not
limited to, taxes, assessments and the like, insurance, utilities,
payroll costs, maintenance, repair and landscaping expenses,
marketing expenses (including an appropriate allocation for legal,
accounts, advertising, marketing and other expenses incurred in
connection with the Project, minus (c) the greater of
(i) actual property management expenses of the Project or
(ii) an amount equal to three percent (3.0%) of the gross
revenues from the Project, minus (d) all rents, common area
reimbursements and other income from the Project received from
tenants in default of obligations under their lease or with respect
to leases as to which the tenant or any guarantor thereunder, is
subject to any bankruptcy, reorganization, arrangement, insolvency,
readjustment of debt, dissolutions, liquidation or similar debtor
relief proceeding. Net Operating Income shall be adjusted to remove
the impact of annual rental escalators as required under GAAP
pursuant to FAS 141, as issued by the Finance Accounting Standards
Board in June of 2001.
Non-Recourse
Indebtedness : As defined in the Revolving Credit
Agreement.
Notes : Promissory
notes, aggregating the Loan Amount, executed by Borrower and
payable to the order of each Lender, in the amount of its
respective Commitment, evidencing the Loan.
Obligations . All
indebtedness, obligations and liabilities of the Borrower to any of
the Lenders or the Agent existing on the date of this Agreement or
arising thereafter, direct or indirect, joint or several, absolute
or contingent, matured or unmatured, liquidated or unliquidated,
secured or unsecured, arising by contract, operation of law or
otherwise, in each case arising or incurred under this Agreement or
any of the other Loan Documents or in respect of any disbursements
of the Loan or the Notes or other instruments at any time
evidencing any thereof.
12
OFAC : Office of
Foreign Asset Control of the Department of the Treasury of the
United States of America
OFAC Review Process :
That certain review process established by Agent to determine if
any potential transferee of any interests or any assignee of any
portion of the Loan or any of their members, officers or partners
are a party with whom Agent and any Lender are restricted from
doing business under (i) the regulations of OFAC, including
those Persons named on OFAC’s Specially Designated and
Blocked Persons list, or (ii) any other statute, executive
order or other governmental action or list (including the
September 24, 2001 Executive Order Blocking Property and
Prohibiting Transactions With Persons Who Commit, Threaten to
Commit, or Support Terrorism).
Opening of the Loan or
Loan Opening : The first disbursement of Loan
proceeds.
Patriot Act Customer
Identification Process : That certain customer identification
and review process established by the Agent pursuant to the
requirements of 31 U.S.C. §5318(1) and 31 C.F.R. §103.121
to verify the identity of all permitted transferees of interests in
the Borrower and any assignees of a portion of the Loan
hereunder.
Percentage : With
respect to each Lender, the percentage that its Commitment
constitutes of the maximum amount of the Loan.
Permitted Exceptions :
Those matters listed on Exhibit B to which title to the
Project may be subject at the date of this Agreement and thereafter
such other title exceptions as Lender may reasonably approve in
writing.
Permitted Liens : As
defined in the Revolving Credit Agreement.
Person : Any
individual, corporation, limited liability company, partnership,
trust, unincorporated association, business, or other legal entity,
and any government or any governmental agency or political
subdivision thereof.
Plans and
Specifications : Detailed plans and specifications for the
Improvements, as approved by Agent pursuant to
Section 9.1(f) , as modified hereafter with
Agent’s prior written approval or as otherwise expressly
permitted by this Agreement.
Power Agreements :
Collectively, (i) the letter agreement dated June 15,
2006 by and between DuPont Fabros Development LLC and Commonwealth
Edison Company, (ii) the Memorandum of Understanding dated
August 7, 2006 by and between DuPont Fabros Development LLC
and Commonwealth Edison Company, (iii) the Memorandum of
Understanding dated September 28, 2006 by and between DuPont
Fabros Development LLC and Commonwealth Edison Company and
(iv) the letter from dated November 7, 2007 from
Commonwealth Edison Company to DuPont Fabros (collectively, the
“ComEd Documents”), as such ComEd Documents have been
assigned to Borrower pursuant to that certain Assignment and
Assumption of Contracts dated as of February 28,
2007.
13
Prime Rate : That
interest rate established from time to time by KeyBank National
Association as its prime rate, whether or not such rate is publicly
announced; the Prime Rate may not be the lowest interest rate
charged by KeyBank National Association for commercial or other
extensions of credit;
Pro-Forma Projection :
A pro forma statement of projected income and expenses of the
Project.
Project : The
collective reference to (i) the Land, together with all
buildings, structures and improvements located or to be located
thereon, including the Improvements, (ii) all rights,
privileges, easements and hereditaments relating or appertaining
thereto, and (iii) all personal property, fixtures and
equipment required or beneficial for the operation
thereof.
REIT : DuPont Fabros
Technology, Inc., a Maryland real estate investment
trust.
REIT Status . With
respect to REIT, its status as a real estate investment trust as
defined in §856(a) of the Code.
Record : The grid
attached to any Note, or the continuation of such grid, or any
other similar record, including computer records, maintained by
Agent with respect to any Loan referred to in such Note.
Release : As defined
in Section 3.1(m)(iii) of this Agreement.
Required Lenders :
Lenders holding Percentages aggregating at least sixty-six and
two-thirds percent (66.66%).
Required Permits :
Each building permit, certificate of occupancy, environmental
permit, air emission or air quality permit, utility permit, land
use permit, wetland permit and any other permits, approvals or
licenses issued by any Governmental authority which are required in
connection the Construction or operation of the Project.
Reserve Percentage :
For any LIBOR Rate Interest Period, that percentage which is
specified three (3) Business Days before the first day of such
LIBOR Rate Interest Period by the Board of Governors of the Federal
Reserve System (or any successor) or any other governmental or
quasi-governmental authority with jurisdiction over Lender for
determining the maximum reserve requirement (including, but not
limited to, any marginal reserve requirement) for Lender with
respect to liabilities constituting of or including (among other
liabilities) Eurocurrency liabilities in an amount equal to that
portion of the Loan affected by such LIBOR Rate Interest Period and
with a maturity equal to such LIBOR Rate Interest
Period.
Revolving Credit
Agreement : The Credit Agreement dated August 7, 2007, by
and among Safari Ventures LLC, as parent borrower, Rhino Equity
LLC, Quill Equity LLC, Lemur Properties LLC, Porpoise Ventures LLC,
each a subsidiary borrower, KeyBank, individually and as Agent, and
the other banks from time to time a party thereto, as affected by
the Consent and Assumption Agreement, as such agreement exists as
of the date hereof. In the event that the
14
Revolving Credit Agreement shall
terminate or otherwise be of no force or effect, then the
obligation of Borrower and Guarantor hereunder to perform each and
every covenant therein shall survive notwithstanding such
termination. In the event that the Revolving Credit Agreement shall
be modified or any of the provisions thereof shall be waived, and
the Required Lenders shall have approved the amendment or waiver
thereunder in writing, then such amendment or waiver shall be
deemed to be a part of the definition of Revolving Credit
Agreement.
S&P :
Standard & Poor’s Ratings Group.
Security Documents :
The Mortgage, the Assignment of Rents, the Environmental Indemnity,
the Guaranty, and any other agreement, document or instrument now
or hereafter securing the Obligations.
Soil Report : A soil
test report prepared by licensed engineer satisfactory to Agent to
the satisfaction of Agent that the soil and subsurface conditions
underlying the Project will support the Improvements.
State : The state in
which the Land is located.
Subcontracts :
Subcontracts for labor or materials to be furnished to the
Project.
Subsidiary : For any
Person, any corporation, partnership, limited liability company or
other entity of which at least a majority of the securities or
other ownership interests having by the terms thereof ordinary
voting power to elect a majority of the board of directors or other
persons performing similar functions of such corporation,
partnership, limited liability company or other entity (without
regard to the occurrence of any contingency) is at the time
directly or indirectly owned or controlled by such Person or one or
more Subsidiaries of such Person or by such Person and one or more
Subsidiaries of such Person, and shall include all Persons the
accounts of which are consolidated with those of such Person
pursuant to GAAP.
Taking : Any
condemnation for public use of, or damage by reason of, the action
of any Governmental Authority, or any transfer by private sale in
lieu thereof, either temporarily or permanently.
Tenant : The tenant
under a Lease.
Title Insurer :
Commonwealth Land Title Insurance Company, or such other title
insurance company licensed in the State as may be approved in
writing by Lender.
Title Policy : An ALTA
Mortgagee’s Loan Title Insurance Policy with extended
coverage issued by the Title Insurer insuring the lien of the
Mortgage as a valid first, prior and paramount lien upon the
Project and all appurtenant easements, and subject to no other
exceptions other than the Permitted Exceptions.
Total Annual Debt
Service : The aggregate of debt service payments for a 12 month
period on the stated principal amount of the Loan, assuming
(i) a per annum interest rate (herein, “Assumed
Rate”) equal to the greater of (x) seven percent
(7.00%), and (y) two percent (2.00%)
15
above the yield on ten year United
States Treasury notes as of the close of business on the day
preceding the date of calculation, as announced on Bloomberg.com or
another reliable source selected by the Agent, and
(ii) monthly payments of principal and interest based on an
amortization period of twenty-five (25) years.
Transfer : Any sale,
transfer, lease (other than an approved Lease or a Lease approved
(or deemed approved) by Agent), conveyance, alienation, pledge,
assignment, mortgage, encumbrance hypothecation or other
disposition of (a) all or any portion of the Project or any
portion of any other security for the Loan, (b) all or any
portion of the Borrower’s right, title and interest (legal or
equitable) in and to the Project or any portion of any other
security for the Loan, or (c) any interest in Borrower or any
interest Tarantula Interests LLC, a Delaware limited liability
company, or Safari Ventures LLC, a Delaware limited liability
company (but expressly excluding any transfers of limited
partnership interests in Guarantor or the transfers of stock in the
REIT).
Unavoidable Delay :
Any delay in the construction of the Project, caused by natural
disaster, fire, earthquake, floods, explosion, extraordinary
adverse weather conditions, inability to procure or a general
shortage of labor, equipment, facilities, energy, materials or
supplies in the open market, failure of transportation, strikes or
lockouts for which Borrower has notified Agent in
writing.
Voting Interests :
Shares of capital stock issued by a corporation, or equivalent
Equity Interests in any other Person, the holders of which are
ordinarily, in the absence of contingencies, entitled to vote for
the election of directors (or persons performing similar functions)
of such Person, even if the right so to vote has been suspended by
the happening of such a contingency.
| 2.2 |
Other Definitional Provisions . |
All terms defined in this
Agreement shall have the same meanings when used in the Notes,
Mortgage, any other Loan Documents, or any certificate or other
document made or delivered pursuant hereto. The words
“hereof”, “herein” and
“hereunder” and words of similar import when used in
this Agreement shall refer to this Agreement.
ARTICLE 3
BORROWER’S
REPRESENTATIONS AND WARRANTIES
| 3.1 |
Representations and Warranties . |
To induce Agent and Lender to
execute this Agreement and perform its obligations hereunder,
Borrower hereby represents and warrants to Agent and Lender as
follows:
(a) Borrower has good and
marketable fee simple title to the Project, subject only to the
Permitted Exceptions.
(b) Except as previously
disclosed to Agent in writing, no litigation or proceedings are
pending, or to the best of Borrower’s knowledge threatened,
against Borrower or Guarantor, which could, if adversely
determined, cause a Material Adverse Change with respect to
Borrower, Guarantor or the Project. There are no Environmental
Proceedings and Borrower has no knowledge of any threatened
Environmental Proceedings or any facts or circumstances which may
give rise to any future Environmental Proceedings.
16
(c) Borrower is a duly
organized and validly existing Delaware limited liability company
and has full power and authority to execute, deliver and perform
all Loan Documents to which Borrower is a party, and such
execution, delivery and performance have been duly authorized by
all requisite action on the part of Borrower.
(d) No consent, approval or
authorization of or declaration, registration or filing with any
Governmental Authority or nongovernmental person or entity,
including any creditor, partner, or member of Borrower or
Guarantor, is required in connection with the execution, delivery
and performance of this Agreement or any of the Loan Documents
other than the recordation of the Mortgage, Assignment of Leases
and Rents and the filing of UCC-1 Financing Statements, except for
such consents, approvals or authorizations of or declarations or
filings with any Governmental Authority or non-governmental person
or entity where the failure to so obtain would not have an adverse
effect on Borrower or such Guarantor or which have been obtained as
of any date on which this representation is made or
remade.
(e) The execution, delivery
and performance of this Agreement, the execution and payment of the
Notes and the granting of the Mortgage and other security interests
under the other Loan Documents have not constituted and will not
constitute, upon the giving of notice or lapse of time or both, a
breach or default under any other agreement to which Borrower or
Guarantor is a party or may be bound or affected, or a violation of
any law or court order which may affect the Project, any part
thereof, any interest therein, or the use thereof.
(f) There is no default under
this Agreement or any of the other Loan Documents, nor any
condition which, after notice or the passage of time or both, would
constitute a default or an Event of Default under said
documents.
(g) (i) No condemnation
of any portion of the Project, (ii) no condemnation or
relocation of any roadways abutting the Project, (iii) no
proceeding to deny access to the Project from any point or planned
point of access to the Project, has commenced or, to the best of
Borrower’s knowledge, is contemplated by any Governmental
Authority, and (iv) neither the Project nor any part thereof
is now damaged or injured as result of any fire, explosion,
accident, flood or other casualty.
(h) The amounts set forth in
the Budget present a full and complete itemization by category of
all costs, expenses and fees which Borrower reasonably expects to
pay or reasonably anticipates becoming obligated to pay to complete
the Construction and operate the Project (until the Project
achieves breakeven operations). Borrower is unaware of any other
such costs, expenses or fees which are material and are not covered
by the Budget.
(i) Neither the construction
of the Improvements nor the use of the Project when completed and
the contemplated accessory uses will violate (i) any Laws
(including subdivision, zoning, building, environmental protection
and wetland protection Laws), or (ii) any building permits,
restrictions of record, or agreements affecting the Project or any
part thereof. Neither the zoning authorizations, approvals or
variances nor any other right to construct or to use the
17
Project is to any extent dependent upon
or related to any real estate other than the Land. All Governmental
Approvals required for the Construction in accordance with the
Plans and Specifications have been obtained or will be obtained
prior to the earlier of (i) the Loan Opening, or
(ii) commencement of Construction of such work, except for
those approved by Agent, and all Laws relating to the Construction
and operation of the Improvements have been complied with and all
permits and licenses required for the operation of the Project
which cannot be obtained until the Construction is completed can be
obtained if the Improvements are completed in accordance with the
Plans and Specifications.
(j) The Project will have
adequate water, gas and electrical supply (not less than 18.2
megawatts of critical load power), storm and sanitary sewerage
facilities, other required public utilities, fire and police
protection, and means of access between the Project and public
highways; none of the foregoing will be foreseeably delayed or
impeded by virtue of any requirements under any applicable Laws. No
such utility services are subject to any moratorium, or, to the
best of Borrower’s knowledge, would be subject to any
threatened moratorium, imposed by any authority having
jurisdiction.
(k) No brokerage fees or
commissions are payable by or to any person in connection with this
Agreement or the Loan to be disbursed hereunder.
(l) All financial statements
and other information previously furnished by Borrower or Guarantor
to Agent in connection with the Loan are true, complete and correct
and fairly present the financial conditions of the subjects thereof
as of the respective dates thereof and do not fail to state any
material fact necessary to make such statements or information not
misleading, and no Material Adverse Change with respect to Borrower
or Guarantor has occurred since the respective dates of such
statements and information. Neither Borrower nor Guarantor has any
material liability, contingent or otherwise, not disclosed in such
financial statements.
(m) The Borrower has taken
all commercially reasonable steps to investigate the past and
present conditions and usage of the Project and the operations
conducted thereon and, except as specifically set forth in the
written environmental site assessment reports of the Environmental
Engineer provided to the Agent on or before the date hereof, makes
the following representations and warranties:
(i) Neither the Borrower, nor
to the best knowledge and belief of Borrower, any operator of the
Project, nor any Tenant or operations thereon, is in violation, or
alleged violation, of any judgment, decree, order, law, license,
rule or regulation pertaining to environmental matters, including
without limitation, those arising under any Environmental Law,
which violation involves the Project.
(ii) The Borrower has not
received notice from any third party including, without limitation,
any federal, state or local governmental authority, (i) that
it has been identified by the United States Environmental
Protection Agency (“EPA”) as a potentially responsible
party under CERCLA with respect to a site listed on the National
Priorities List, 40 C.F.R. Part 300 Appendix B (1986);
(ii) that any Hazardous Substance(s) which it has generated,
transported or disposed of have been found at any site at which a
federal, state or local agency or
18
other third party has conducted or has
ordered that Borrower conduct a remedial investigation, removal or
other response action pursuant to any Environmental Law; or
(iii) that it is or shall be a named party to any claim,
action, cause of action, complaint, or legal or administrative
proceeding (in each case, contingent or otherwise) arising out of
any third party’s incurrence of costs, expenses, losses or
damages of any kind whatsoever in connection with the release of
Hazardous Substances, which in any case involves the
Project.
(iii) (a) No portion of the
Project has been used for the handling, processing, storage or
disposal of Hazardous Substances except in accordance with
applicable Environmental Laws, and no underground tank or other
underground storage receptacle for Hazardous Substances is located
on any portion of the Project except those which are being operated
and maintained in compliance with Environmental Laws; (b) in
the course of any activities conducted by the Borrower or, to the
best knowledge and belief of the Borrower, the Tenants and
operators of the Project, no Hazardous Substances have been
generated or are being used in the Project except in the ordinary
course of Borrower’s business and in accordance with
applicable Environmental Laws; (c) there has been no past or
present releasing, spilling, leaking, pumping, pouring, emitting,
emptying, discharging, injecting, escaping, disposing or dumping
(other than the storing of materials in reasonable quantities to
the extent necessary for the operation of data centers of the type
and size of those owned by Borrower in the ordinary course of its
business, and in any event in compliance with all Environmental
Laws) (a “Release”) or threatened Release of Hazardous
Substances on, upon, into or from the Project, which Release would
have a Material Adverse Change on the value of the Project or
adjacent properties, which Release has had or could reasonably be
expected to cause a Material Adverse Change; (d) to the
Borrower’s actual knowledge, there have been no Releases on,
upon, from or into any real property in the vicinity of the Project
which, through soil or groundwater contamination, may have come to
be located on, and which could be reasonably anticipated to cause a
Material Adverse Change on the value of, the Project; and
(e) any Hazardous Substances that have been generated on the
Project have been transported off site in accordance with all
applicable Environmental Laws.
(iv) Neither the Borrower nor
the Project is subject to any applicable Environmental Law
requiring the performance of Hazardous Substances site assessments,
or the removal or remediation of Hazardous Substances, or the
giving of notice to any governmental agency or the recording or
delivery to other Persons of an environmental disclosure document
or statement in each case by virtue of the transactions set forth
herein and contemplated hereby, or as a condition to the recording
of the Mortgage or to the effectiveness of any other transactions
contemplated hereby except for such matters that shall be complied
with as of the Opening of the Loan.
(v) There are no existing or
closed sanitary landfills, solid waste disposal sites, or hazardous
waste treatment, storage or disposal facilities on or, to
Borrower’s actual knowledge, affecting the
Project.
(vi) The Borrower has not
received any written notice of any claim by any party that any use,
operation, or condition of the Project has caused any nuisance or
any other liability or adverse condition on any other property, nor
is there any actual knowledge of any basis for such a
claim
19
(n) The Project is taxed
separately without regard to any other property and for all
purposes the Project may be mortgaged, conveyed and otherwise dealt
with as an independent parcel.
(o) Except for Leases which
have been provided to and approved by Agent in writing (or deemed
approved), or which are Approved Leases, Borrower and its agents
have not entered into any Leases, subleases or other arrangements
for occupancy of space within the Project. True, correct and
complete copies of all Leases, as amended, have been delivered to
Lender. All Leases are in full force and effect. Neither Borrower
nor any Tenant is in default under any Lease and Borrower has
disclosed to Lender in writing any material default by the tenant
under any Lease. As of the Opening of the Loan, there are no Leases
at the Project.
(p) When the Construction is
completed in accordance with the Plans and Specifications, no
building or other improvement will encroach upon any property line,
building line, setback line, side yard line or any recorded or
visible easement (or other easement of which Borrower is aware or
has reason to believe may exist) with respect to the
Project.
(q) The Loan is not being
made for the purpose of purchasing or carrying “margin
stock” within the meaning of Regulation T, U or X issued
by the Board of Governors of the Federal Reserve System, and
Borrower agrees to execute all instruments necessary to comply with
all the requirements of Regulation U of the Federal Reserve
System.
(r) Borrower is not a party
in interest to any plan defined or regulated under ERISA, and the
assets of Borrower are not “plan assets” of any
employee benefit plan covered by ERISA or Section 4975 of the
Internal Revenue Code.
(s) Borrower is not a
“foreign person” within the meaning of
Section 1445 or 7701 of the Internal Revenue Code.
(t) Borrower uses no trade
name other than its actual name set forth herein. The principal
place of business of Borrower is as stated in
Article 22 .
(u) Borrower’s place of
formation or organization is the State of Delaware. Tarantula
Interests LLC, a Delaware limited liability company, is the sole
member of the Borrower.
(v) All statements set forth
in the Recitals are true and correct.
(w) Neither Borrower nor
Guarantor is (or will be) a person with whom Lender is restricted
from doing business under OFAC (including, those Persons named on
OFAC’s Specially Designated and Blocked Persons list) or
under any statute, executive order (including, the
September 24, 2001 Executive Order Blocking Property and
Prohibiting Transactions With Persons Who Commit, Threaten to
Commit, or Support Terrorism), or other governmental action and is
not and shall not engage in any dealings or transactions or
otherwise be associated with such persons. In addition, Borrower
hereby agrees to provide to the Lender with any additional
information that the Lender deems necessary from time to time in
order to ensure compliance with all applicable Laws concerning
money laundering and similar activities.
20
(x) The execution and
delivery of this Agreement and the other Loan Documents to which
the Borrower or the Guarantor are to become a party will result in
valid and legally binding obligations of such Person enforceable
against it in accordance with the respective terms and provisions
hereof and thereof, except as enforceability is limited by
bankruptcy, insolvency, reorganization, moratorium or other laws
relating to or affecting generally the enforcement of
creditors’ rights and except to the extent that availability
of the remedy of specific performance or injunctive relief is
subject to the discretion of the court before which any proceeding
therefor may be brought.
(y) The Project is not owned
or operated under or by reference to any registered or protected
trademark, tradename, servicemark or logo.
(z) Neither the Borrower nor
the Guarantor is an “investment company”, or an
“affiliated company” or a “principal
underwriter” of an “investment company”, as such
terms are defined in the Investment Company Act of 1940.
(aa) As of the date of this
Agreement and after giving effect to the transactions contemplated
by this Agreement and the other Loan Documents, including all Loans
made or to be made hereunder, the Borrower is not insolvent on a
balance sheet basis such that the sum of such Person’s assets
exceeds the sum of such Person’s liabilities, the Borrower is
able to pay its debts as they become due, and the Borrower has
sufficient capital to carry on its business.
(bb) Each of the contracts
for construction of the Project is in full force and effect and the
Borrower and the other parties thereto are in compliance with their
respective obligations therein.
(cc) There are no unpaid or
outstanding real estate or other taxes or assessments on or against
the Project or any part thereof which are payable by the Borrower.
No abatement proceedings are pending with reference to any real
estate taxes assessed against the Project. To the best of
Borrower’s knowledge, there are no betterment assessments or
other special assessments presently pending with respect to any
part of the Project, and the Borrower has received no written
notice of any such special assessment being
contemplated.
(dd) The Borrower has
received no notice of, and otherwise has no knowledge of, any
violation of any material agreement affecting the Borrower or the
Project.
(ee) The Borrower has
furnished the Agent with true and complete sets of the Plans and
Specifications to date. The Plans and Specifications so furnished
to the Agent comply (and the Improvements when constructed in
substantial accordance with the Plans and Specifications will
likewise comply) with all Laws, all Government Approvals, and all
restrictions, covenants, easements and other agreements affecting
the Project, and have been approved by each Governmental Authority
only to the extent required for construction of the
Improvements.
(ff) The Budget accurately
reflects all Budget Line Items as of the date thereof or as of the
date of any amendments thereto, as applicable.
(gg) The Borrower has not
received any written notice from any insurer or its agent requiring
performance of any work with respect to the Land or the
Improvements or canceling or threatening to cancel any policy of
insurance, and the Project complies with the requirements of the
Borrower’s and each General Contractor’s insurance
carriers, as applicable.
21
(hh) All of the
representations and warranties made by or on behalf of the Borrower
or the Guarantor in this Agreement and the other Loan Documents or
any document or instrument delivered by or on behalf of Borrower or
Guarantor to the Agent or the Lenders pursuant to or in connection
with any of such Loan Documents are true and correct in all
material respects, and none of the Borrower or the Guarantor has
failed to disclose such information as is necessary to make such
representations and warranties not misleading.
| 3.2 |
Survival of Representations and Warranties
. |
Borrower agrees that all of
the representations and warranties set forth in
Section 3.1 and elsewhere in this Agreement are true as
of the date hereof, will be true at the Loan Opening and, except
for matters which have been disclosed by Borrower and approved by
Agent in writing, at all times thereafter. Each request for a
disbursement under the Loan Documents shall constitute a
reaffirmation of such representations and warranties, as deemed
modified in accordance with the disclosures made and approved as
aforesaid, as of the date of such request. It shall be a condition
precedent to the Loan Opening and each subsequent disbursement that
each of said representations and warranties is true and correct as
of the date of such requested disbursement. Each request for
disbursement of Loan proceeds shall be deemed to be a reaffirmation
by Borrower that each of the representations and warranties is true
and correct as of the date of such disbursement. In addition, at
Agent’s request, Borrower shall reaffirm such representations
and warranties in writing prior to each disbursement
hereunder.
ARTICLE 4
LOAN AND LOAN
DOCUMENTS
| 4.1 |
Agreement to Borrow and Lend; Lender’s Obligation
to Disburse . |
Subject to the terms,
provisions and conditions of this Agreement and the other Loan
Documents, Borrower agrees to borrow from Lender and Lender agrees
to lend to Borrower the Loan, for the purposes and subject to all
of the terms, provisions and conditions contained in this
Agreement. If Lender consists of more than one party, the
obligations of each such party with respect to the amount it has
agreed to loan to Borrower shall be several (and not joint and
several) and shall be limited to its Percentage of the Loan and of
each advance.
(a) The principal amount of
the Loan shall not exceed the lesser of (a) One Hundred
Forty-Eight Million Eight Hundred Sixty-Four Thousand Three Hundred
Thirty-Five and No/100 Dollars ($148,864,335.00), (b) 55% of
the Appraised Value of the Project as set out in the Appraisal,
(c) 65% of the total cost of the Project as set out in the
Budget approved by Agent hereunder, or (d) such amount as will
result in a “Debt Service Coverage Ratio” of at least
1.75 to 1.00 (based, for purposes of this calculation, on the
“stabilized” Net Operating Income of the Project
projected in the Appraisal approved by the Lenders).
(b) Lender agrees, upon
Borrower’s compliance with and satisfaction of all conditions
precedent to the Loan Opening and provided the Loan is In Balance,
no Material Adverse Change has occurred and no default or Event of
Default has occurred and is continuing
22
hereunder, to open the Loan to pay or
reimburse Borrower for a portion of the costs incurred by Borrower
in connection with the development of the Project and the
construction of the Improvements, to the extent provided for in the
Budget.
(c) After the Opening of the
Loan, Borrower shall be entitled to receive further successive
disbursements of the proceeds of the Loan in accordance with
Articles 9 , 12 and 13 within ten
(10) Business Days after compliance with all conditions
precedent thereto, provided that (i) the Loan remains In
Balance; (ii) Borrower has complied with all conditions
precedent to disbursement from time to time including the
requirements of Section 3.2 and Articles 8
, 9 , 12 and 13 ; (iii) no Material
Adverse Change has occurred with respect to Borrower, Guarantor,
any Tenant, or the Project and (iv) no Event of Default and no
default exists hereunder or under any other Loan Document or
Lease.
(d) To the extent that Lender
may have acquiesced in noncompliance with any requirements
precedent to the Opening of the Loan or precedent to any subsequent
disbursement of Loan proceeds, such acquiescence shall not
constitute a waiver by Lender, and Lender may at any time after
such acquiescence require Borrower to comply with all such
requirements.
Borrower agrees that it will,
on or before the date of this Agreement, execute and deliver or
cause to be executed and delivered to Lender the following
documents in form and substance acceptable to Lender:
(a) The Loan shall be
evidenced by separate promissory notes of the Borrower to each
Lender in substantially the form of Exhibit C attached
hereto and made a part hereof, dated of even date with this
Agreement and completed with appropriate insertions.
(b) The Mortgage.
(c) The Assignment of
Rents.
(d) The Guaranty.
(e) Indemnity and Guaranty
Agreement.
(f) The Environmental
Indemnity.
(g) A collateral assignment
of construction documents, including, without limitation, the
General Contract, all architecture and engineering contracts, Plans
and Specifications, permits, licenses, approvals and development
rights, together with consents to the assignment and continuation
agreements from the General Contractor, the architect and other
parties reasonably specified by Agent.
(h) Such UCC financing
statements as Agent determines are advisable or necessary to
perfect or notify third parties of the security interests intended
to be created by the Loan Documents.
23
(i) Such other documents,
instruments or certificates as Agent and its counsel may reasonably
require, including such documents as Agent in its sole discretion
deems necessary or appropriate to effectuate the terms and
conditions of this Agreement and the Loan Documents, and to comply
with the laws of the State.
(a) All principal, interest
and other sums due under the Loan Documents shall be due and
payable in full on the Maturity Date. All references herein to the
Maturity Date shall mean the Initial Maturity Date, provided that
Borrower shall have the right to extend the Maturity Date for one
(1) additional twelve (12) month term (the
“Extension Option”), thereby extending the Maturity
Date to the twelve (12) month anniversary of the Initial
Maturity Date (the “Extended Maturity
Date”).
(b) Borrower may only
exercise an Extension Option upon satisfying the following
conditions:
(i) Borrower shall have
delivered to Agent written notice of such election no earlier than
sixty (60) days and no later than thirty (30) prior to
the Initial Maturity Date;
(ii) Agent shall have
received Borrower’s and Guarantor’s current financial
statements, certified as correct by Borrower and Guarantor. There
must be no material adverse change in Borrower’s or
Guarantor’s financial condition;
(iii) Construction of the
Improvements has been substantially completed in accordance with
all requirements of this Loan Agreement including, without
limitation, the Completion Conditions, and a final certificate of
occupancy has been issued;
(iv) Such notice is
accompanied by an extension fee in the amount of 25 basis points
(0.25%) of the Loan Amount;
(v) No Event of Default and
no material Default shall exist; and
(vi) The Debt Service
Coverage Ratio is not less than 1.50: 1.00 (and Borrower shall have
delivered to the Agent a Certificate of Compliance so certifying).
For the purposes of this calculation of Debt Service Coverage Ratio
shall be based upon a pro forma projection of Net Operating Income
for the next four (4) quarters based upon Tenants in occupancy
and estimated annual operating expenses reasonably approved by
Agent.
Borrower shall have the right
to make prepayments of the Loan, in whole or in part, at any time
without prepayment penalty, upon not less than four
(4) days’ prior written notice to Agent. No prepayment
of all or part of the Loan shall be permitted unless same is made
together with the payment of all interest accrued on the Loan
through the date of prepayment and an amount equal to all Breakage
Costs and attorneys’ fees and disbursements incurred by
Lender as a result of the prepayment.
24
| 4.5 |
Required Principal Payments . |
All principal shall be paid
on the Maturity Date.
Any and all amounts due
hereunder or under the other Loan Documents which remain unpaid
more than ten (10) days after the date said amount was due and
payable shall incur a fee (the “Late Charge”) of four
percent (4%) per annum of said amount, which payment shall be
in addition to all of Agent’s and Lender’s other rights
and remedies under the Loan Documents, provided that no Late Charge
shall apply to the final payment of principal on the Maturity
Date.
All payments of principal,
interest, facility fees, closing fees and any other amounts due
hereunder or under any of the other Loan Documents shall be made to
the Agent, for the respective accounts of the Lenders and the
Agent, as the case may be, at the Agent’s Head Office, not
later than 2:00 p.m. (Cleveland time) on the day when due, in each
case in lawful money of the United States in immediately available
funds. The Agent is hereby authorized to charge the accounts of the
Borrower with KeyBank, on the dates when the amount thereof shall
become due and payable, with the amounts of the principal of and
interest on the Loan and all fees, charges, expenses and other
amounts owing to the Agent and/or the Lenders under the Loan
Documents. Subject to the foregoing, all payments made to Agent on
behalf of the Lenders, and actually received by Agent, shall be
deemed received by the Lenders on the date actually received by
Agent.
One Note shall be payable to
the order of each Lender in the principal amount equal to such
Lender’s respective Commitment or, if less, the outstanding
amount of all disbursements of the Loan made by such Lender, plus
interest accrued thereon, as set forth below. The Borrower
irrevocably authorizes Agent to make or cause to be made, at or
about the time of disbursements of the Loan or at the time of
receipt of any payment of principal thereof, an appropriate
notation on Agent’s Record reflecting the making of such
disbursement or (as the case may be) the receipt of such payment.
The outstanding amount of the Loan set forth on Agent’s
Record shall be prima facie evidence of the principal amount
thereof owing and unpaid to such Lender, but the failure to record,
or any error in so recording, any such amount on Agent’s
Record shall not limit or otherwise affect the obligations of the
Borrower hereunder or under any Note to make payments of principal
of or interest on any Note when due.
All payments by the Borrower
to Agent for the account of the Lenders or Agent hereunder and
under any of the other Loan Documents shall be made without setoff
or counterclaim and free and clear of and without deduction for any
taxes, levies, imposts, duties, charges, fees, deductions,
withholdings, compulsory loans, restrictions or conditions of any
nature now or hereafter imposed or levied by any jurisdiction or
any political subdivision thereof or taxing or other authority
therein unless the Borrower is compelled by law to make such
deduction or withholding.
25
ARTICLE 5
INTEREST
(a) The Loan will bear
interest at the Applicable Rate, unless the Default Rate is
applicable. The Adjusted Base Rate shall be the “Applicable
Rate”, except that the Adjusted LIBOR Rate shall be the
“Applicable Rate” with respect to portions of the Loan
as to which a LIBOR Rate Option is then in effect. For each
disbursement of proceeds of the Loan, Borrower shall deliver to
Agent irrevocable notice (which may be (A) verbal notice
provided that Borrower delivers to Agent facsimile confirmation
within twenty four (24) hours of such verbal notice or
(B) electronic mail notice within twenty four (24) hours
of such verbal notice) of the requested amount of such disbursement
(x) if such disbursement is to bear interest at the Adjusted
Base Rate, not later than 11:00 a.m. Cleveland time on the second
Business Day prior to the desired date of disbursement and
(y) if such disbursement is to bear interest at an Adjusted
LIBOR Rate, not later than 11:00 a.m. Cleveland time on the third
(3 rd
) Business Day prior to
the desired date of disbursement. The Borrower promises to pay
interest on the Loan in arrears on the first (1 st ) day of every calendar month in
the amount of all interest accrued and unpaid on each Interest
Payment Date.
(b) Provided that no Event of
Default exists, Borrower shall have the option (the “LIBOR
Rate Option”) to elect from time to time in the manner and
subject to the conditions hereinafter set forth an Adjusted LIBOR
Rate as the Applicable Rate for all or any portion of the Loan
which would otherwise bear interest at the Adjusted Base
Rate.
(c) The only manner in which
Borrower may exercise the LIBOR Rate Option is by giving Agent
irrevocable notice (which may be verbal notice provided that
Borrower delivers to Agent facsimile confirmation in the form of
Exhibit E attached hereto within twenty-four
(24) hours) of such exercise not later than 11:00 a.m.
Cleveland time on the third (3 rd ) LIBOR Business Day prior to the proposed commencement of
the relevant LIBOR Rate Interest Period, which written notice shall
specify: (i) the portion of the Loan with respect to which
Borrower is electing the LIBOR Rate Option, (ii) the LIBOR
Business Day upon which the applicable LIBOR Rate Interest Period
is to commence and (iii) the duration of the applicable LIBOR
Rate Interest Period. The Applicable Rate for any portion of the
Loan with respect to which Borrower has elected the LIBOR Rate
Option shall revert to the Adjusted Base Rate as of the last day of
the LIBOR Rate Interest Period applicable thereto (unless Borrower
again exercises the LIBOR Rate Option for such portion of the
Loan). Agent shall be under no duty to notify Borrower that the
Applicable Rate on any portion of the Loan is about to revert from
an Adjusted LIBOR Rate to the Adjusted Base Rate. The LIBOR Rate
Option may be exercised by Borrower only with respect to any
portion of the Loan equal to or in excess of $500,000. At no time
may there be more than six (6) LIBOR Rate Interest Periods in
effect with respect to the Loan. Notwithstanding the foregoing, if
Borrower shall elect a LIBOR Rate Option, only so much of the
outstanding principal amount of the Loan as would not become due
and payable during the applicable LIBOR Rate Interest Period shall
accrue interest at the Adjusted LIBOR Rate and the remaining
principal balance shall accrue interest at the Adjusted Base
Rate.
26
(d) If Agent determines
(which determination shall be conclusive and binding upon Borrower,
absent manifest error) (i) that Dollar deposits in an amount
approximately equal to the portion of the Loan for which Borrower
has exercised the LIBOR Rate Option for the designated LIBOR Rate
Interest Period are not generally available at such time in the
London interbank market for deposits in Dollars, (ii) that the
rate at which such deposits are being offered will not adequately
and fairly reflect the cost to Lender of maintaining a LIBOR Rate
on such portion of the Loan or of funding the same for such LIBOR
Rate Interest Period due to circumstances affecting the London
interbank market generally, (iii) that reasonable means do not
exist for ascertaining a LIBOR Rate, or (iv) that an Adjusted
LIBOR Rate would be in excess of the maximum interest rate which
Borrower may by law pay, then, in any such event, Agent shall so
notify Borrower and all portions of the Loan bearing interest at an
Adjusted LIBOR Rate that are so affected shall, as of the date of
such notification with respect to an event described in
clause (ii) or (iv) above, or as of the
expiration of the applicable LIBOR Rate Interest Period with
respect to an event described in clause (i) or
(iii) above, bear interest at the Adjusted Base Rate
until such time as the situations described above are no longer in
effect or can be avoided by Borrower exercising a LIBOR Rate Option
for a different LIBOR Rate Interest Period.
(e) Interest at the
Applicable Rate (or Default Rate) shall be calculated for the
actual number of days elapsed on the basis of a 360-day year, (or a
365- or 366- day year, as applicable, in the case of the Adjusted
Base Rate) including the first date of the applicable period to,
but not including, the date of repayment. Whenever a payment
hereunder or under any of the other Loan Documents becomes due on a
day that is not a Business Day, the due date for such payment shall
be extended to the next succeeding Business Day, and interest shall
accrue during such extension.
(f) Borrower shall pay all
Breakage Costs incurred from time to time by Lender upon demand
within fifteen (15) Business Days of receipt of written notice
from Agent.
(g) If the introduction of or
any change in any Law, regulation or treaty, or in the
interpretation thereof by any Governmental Authority charged with
the administration or interpretation thereof, shall make it
unlawful for Lender to maintain the Applicable Rate at an Adjusted
LIBOR Rate with respect to the Loan or any portion thereof, or to
fund the Loan or any portion thereof in Dollars in the London
interbank market, or to give effect to its obligations regarding
the LIBOR Rate Option as contemplated by the Loan Documents, then
(1) Agent shall notify Borrower that Lender is no longer able
to maintain the Applicable Rate at an Adjusted LIBOR Rate,
(2) the LIBOR Rate Option shall immediately terminate,
(3) the Applicable Rate for any portion of the Loan for which
the Applicable Rate is then an Adjusted LIBOR Rate shall
automatically be converted to the Adjusted Base Rate, and
(4) Borrower shall pay to Agent the amount of Breakage Costs
(if any) incurred by Lender in connection with such conversion.
Thereafter, Borrower shall not be entitled to exercise the LIBOR
Rate Option until such time as the situation described herein is no
longer in effect or can be avoided by Borrower exercising a LIBOR
Rate Option for a LIBOR Rate Interest Period.
(h) Notwithstanding anything
in this Agreement or the other Loan Documents to the contrary, all
agreements between or among the Borrower, the Guarantor, the Lender
and the Agent, whether now existing or hereafter arising and
whether written or oral, are hereby limited so that in no
contingency, whether by reason of acceleration of the maturity of
any of the
27
Obligations or otherwise, shall the
interest contracted for, charged or received by the Lender exceed
the maximum amount permissible under applicable law. If, from any
circumstance whatsoever, interest would otherwise be payable to the
Lender in excess of the maximum lawful amount, the interest payable
to the Lender shall be reduced to the maximum amount permitted
under applicable law; and if from any circumstance the Lender shall
ever receive anything of value deemed interest by applicable law in
excess of the maximum lawful amount, an amount equal to any
excessive interest shall be applied to the reduction of the
principal balance of the Obligations and to the payment of interest
or, if such excessive interest exceeds the unpaid balance of
principal of the Obligations, such excess shall be refunded to the
Borrower. All interest paid or agreed to be paid to the Lender
shall, to the extent permitted by applicable law, be amortized,
prorated, allocated and spread throughout the full period until
payment in full of the principal of the Obligations (including the
period of any renewal or extension thereof) so that the interest
thereon for such full period shall not exceed the maximum amount
permitted by applicable law. The Borrower agrees to pay an
effective rate of interest that is the sum of the applicable rate
as stated in this Agreement plus any additional rate of interest
resulting from any charges of interest or in the nature of interest
paid or to be paid in connection with any of the Loan Documents.
This Section shall control all agreements between or among the
Borrower, the Guarantor, the Lender and the Agent.
| 5.2 |
[Intentionally Omitted.] |
ARTICLE 6
COSTS OF MAINTAINING
LOAN
| 6.1 |
Increased Costs and Capital Adequacy
. |
(a) Borrower recognizes that
the cost to Lender of maintaining the Loan or any portion thereof
may fluctuate and, Borrower agrees to pay Agent additional amounts
to compensate Lender for any increase in its actual costs incurred
in maintaining the Loan or any portion thereof outstanding or for
the reduction of any amounts received or receivable from Borrower
as a result of:
(i) any change after the date
hereof in any applicable Law, regulation or treaty, or in the
interpretation or administration thereof, or by any domestic or
foreign court, (A) changing the basis of taxation of payments
under this Agreement to Lender (other than taxes imposed on all or
any portion of the overall net income or receipts of Lender), or
(B) imposing, modifying or applying any reserve, special
deposit or similar requirement against assets of, deposits with or
for the account of, credit extended by, or any other acquisition of
funds for loans by Lender (which includes the Loan or any
applicable portion thereof) ( provided , however ,
that Borrower shall not be charged again the Reserve Percentage
already accounted for in the definition of the Adjusted LIBOR
Rate), or (C) imposing on Lender, or the London interbank
market generally, any other condition affecting the Loan, provided
that the result of the foregoing is to increase the cost to Lender
of maintaining the Loan or any portion thereof or to reduce the
amount of any sum received or receivable from Borrower by Lender
under the Loan Documents; or
28
(ii) the maintenance by a
Lender of reserves in accordance with reserve requirements
promulgated by the Board of Governors of the Federal Reserve System
of the United States with respect to “Eurocurrency
Liabilities” of a similar term to that of the applicable
portion of the Loan (without duplication for reserves already
accounted for in the calculation of a LIBOR Rate pursuant to the
terms hereof).
(b) If the application of any
Law, rule, regulation or guideline adopted or arising out of the
report of the Basle Committee on Banking Regulations and
Supervisory Practices entitled “International Convergence of
Capital Measurement and Capital Standards”, or the adoption
after the date hereof of any other Law, rule, regulation or
guideline regarding capital adequacy, or any change after the date
hereof in any of the foregoing, or in the interpretation or
administration thereof by any domestic or foreign Governmental
Authority, central bank or comparable agency charged with the
interpretation or administration thereof, or compliance by any
Lender, with any request or directive regarding capital adequacy
(whether or not having the force of law) of any such authority,
central bank or comparable agency, has the effect of reducing the
rate of return on such Lender’s capital to a level below that
which such Lender would have achieved but for such application,
adoption, change or compliance (taking into consideration the
policies of such Lender with respect to capital adequacy), then,
from time to time Borrower shall pay to such Lender such additional
amounts as will compensate such Lender for such reduction with
respect to any portion of the Loan outstanding.
(c) Any amount payable by
Borrower under subsection (a) or
subsection (b) of this Section 6.1 shall be
paid within five (5) days of receipt by Borrower of a
certificate signed by an authorized officer of Agent setting forth
the amount due and the basis for the determination of such amount,
which statement shall be conclusive and binding upon Borrower,
absent manifest error. Failure on the part of Agent to demand
payment from Borrower for any such amount attributable to any
particular period shall not constitute a waiver of Lender’s
right to demand payment of such amount for any subsequent or prior
period. Agent shall use reasonable efforts to deliver to Borrower
prompt notice of any event described in subsection (a)
or (b) above, of the amount of the reserve and capital
adequacy payments resulting therefrom and the reasons therefor and
of the basis of calculation of such amount; provided ,
however , that any failure by Agent so to notify Borrower
shall not affect Borrower’s obligation to pay the reserve and
capital adequacy payment resulting therefrom.
| 6.2 |
Borrower Withholding . |
If by reason of a change in
any applicable Laws occurring after the date hereof, Borrower is
required by Law to make any deduction or withholding in respect of
any taxes (other than taxes imposed on or measured by the net
income of Lender or any franchise tax imposed on Lender), duties or
other charges from any payment due under the Notes to the maximum
extent permitted by law, the sum due from Borrower in respect of
such payment shall be increased to the extent necessary to ensure
that, after the making of such deduction or withholding, Lender
receives and retains a net sum equal to the sum which it would have
received had no such deduction or withholding been required to be
made.
29
ARTICLE 7
LOAN EXPENSE AND
ADVANCES
| 7.1 |
Loan and Administration Expenses . |
Borrower unconditionally
agrees to pay all expenses of the Loan, including all amounts
payable pursuant to Sections 7.2 , 7.3 and
7.4 and any and all other fees owing to Agent or Lender
pursuant to the Loan Documents or any separate fee agreement, and
also including, without limiting the generality of the foregoing,
all recording, filing and registration fees and charges, mortgage
or documentary taxes, all insurance premiums, title insurance
premiums and other charges of the Title Insurer, printing and
photocopying expenses, survey fees and charges, cost of certified
copies of instruments, cost of premiums on surety company bonds and
the Title Policy, charges of the Title Insurer or other escrowee
for administering disbursements, all fees and disbursements of
Lender’s Consultant, all appraisal fees, insurance
consultant’s fees, environmental consultant’s fees,
travel related expenses and all costs and expenses incurred by
Agent and Lender in connection with the determination of whether or
not Borrower has performed the obligations undertaken by Borrower
hereunder or has satisfied any conditions precedent to the
obligations of Lender hereunder and, if any default or Event of
Default occurs hereunder or under any of the Loan Documents or if
the Loan or Notes or any portion thereof is not paid in full when
and as due, all costs and expenses of Agent and Lender (including,
without limitation, court costs and counsel’s fees
and
|